Legal Notices for week of October 25
Legal Notice
REQUEST FOR LETTERS
OF INTEREST
The Calhoun County Board of County Commissioners will receive Letters of Interest from any qualified engineering and surveying firm interested in providing the requested services for the following project:
ALTHA SIDEWALK
CONSTRUCTION ENGINEERING AND INSPECTION SERVICES
The project will consist of construction engineering and inspection of the sidewalk and minor drainage improvements along Smith Street, Fuqua Circle and North Street within the Town limits of Altha in accordance with FDOT Standards as identified in the County’s Local Agency Participation contract with FDOT.
The Proposer’s Checklist can be obtained at the Emergency Management Office, 20859 Central Avenue East, Room G40 (located in the basement of the Courthouse), Blountstown, Florida. All questions concerning the checklist can be addressed to Angie Smith (850) 674-8075.
Plans and specifications may be viewed or obtained at Preble-Rish, Inc., 20684 Central Ave. East Blountstown, FL 32424, (850) 674-3300. Cost for plans and specifications will be $50 per set and is non-refundable. Checks should be made payable to Preble-Rish, Inc. Questions concerning the plans or specifications should be addressed to Kristin Brown P.E. (850) 674-3300.
This project is federally funded with assistance from the Florida Department of Transportation (FDOT) and the Federal Highway Administration (FHWA). Conflicts of interest will be governed by FDOT Procedure No. 375-030-006 (Restriction on Consultants Eligibility to Compete for Department Contracts).
Letters of interest will be received until 3:00 p.m. Central Standard Time, on Monday, November 5, 2012, at the, Calhoun County Courthouse, Clerk of Court Office, 20859 Central Avenue East, Room 130, Blountstown, Florida.
Please indicate on the envelope that this is a sealed bid, for the “Altha Sidewalk CEI Services”.
Calhoun County is an Equal Opportunity Employer/Handicapped Accessible/Fair Housing Jurisdiction.
Legal Notice
NOTICE TO RECEIVE SEALED BIDS
The Calhoun County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in providing construction services for the following project:
ALTHA SIDEWALK PROJECT
This project will include the construction of 4,265± LF of 6’ wide sidewalk on North Street, Fuqua Circle and Smith Street within the Altha community. Detectable warnings, thermoplastic striping, and minor drainage improvements are also included.
Plans and specifications can be obtained at Preble-Rish, Inc., 20684 Central Avenue East, Blountstown, Florida 32424, (850) 674-3300 (For questions, please call Kristin Brown at (850) 674-3300). The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
Completion date for this project will be 120 days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day.
Please indicate on the envelope that this is a sealed bid, for the “Altha Sidewalk Project”.
Bids will be received until 12:00 p.m. Central Time, on Tuesday, November 13, 2012, at the Calhoun County Courthouse, Clerk’s Office, 20859 Central Avenue East, Room 130, Blountstown, FL 32424, and will be opened and read aloud on Tuesday, November 13, 2012 at 2:00 p.m. CT. Calhoun County Board of Commissioners is an Equal Opportunity Employer/Handicapped Accessible/Fair Housing Jurisdiction.
Cost for Plans and Specifications will be $50.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC.
The Calhoun County Board of Commissioners reserves the right to reject any and all bids. All Bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida.
This project is federally funded with assistance from the Federal Highway Administration and the Florida Department of Transportation.
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT
IN AND FOR
CALHOUN COUNTY, FLORIDA
CASE NO.: 12-244 CA
IN RE: FORFEITURE OF:
2000 Chevrolet Pickup;
VIN #1 GCCS14W7Y8196981
Robert Lee Miller
NOTICE OF FORFEITURE
PROCEEDING
TO ALL PERSONS WHO CLAIM AN INTEREST IN THE ABOVE-DESCRIBED PROPERTY, WHICH WAS SEIZED ON OR ABOUT SEPTEMBER 12, 2012, IN CALHOUN COUNTY, FLORIDA.
Said property is in the custody of the Blountstown Police Department. Any owner entity, bona fide lienholder or person in possession of the property when seized has the right to contest the Forfeiture Complaint by filing a Response with the Circuit Court within 20 days of the publication of this notice, with a copy of the Response sent to Michelle B. Tagert, Attorney for the Blountstown Police Department, 16908 N.E. Pear Street, Blountstown, Florida 32424. A Petition for Final Order of Forfeiture has been filed in the above-styled cause.
MICHELLE B. TAGERT, ESQ
Fla. Bar No. 70836
BTPleadings@gmail.com (Pleadings)
4431 Lafayette Street
Marianna, FL 32446
850-526-3633 (voice)
850-526-2714 (fax)
Counsel for Blountstown Police Dept.
Legal Notice
REQUEST FOR SEALED BIDS FOR
FOR THE REMOVAL & DISPOSAL
OF FUEL TANK
CITY OF BLOUNTSTOWN
The City of Blountstown is requesting sealed bids for the removal and disposal of an above ground gas/diesel fuel storage tank, to include pumps and canopy. Tank capacity is approximately 5,000 gallons gas, 8,000 gallons diesel. Tank and related components were installed in 2009. Tank can be seen at the City Complex located at 17262 NW Angle St., Blountstown, FL 32424. Please contact Emory Pierce, City Manager at epierce@blountstown.org or (850) 674-5488 for additional details.
Sealed bids marked “FUEL TANKS’ must be received by 2:00 P.M. C.S.T., on Tuesday, November 13, 2012 at City Hall, Attention: City Manager, 20591 Central Ave. W., Blountstown, FL 32424. Bids will then be opened and read aloud during the Regular Session of the City Council on Tuesday, November 13, 2012 at 17276 NW Angle Street, Blountstown, Florida 32424. Bid opening will begin at 6:00 P.M., C.S.T. The City reserves the right to accept all or any part of the Bid(s) deemed in the best interest of the City and to reject any or all Bids.
FROM: Emory Pierce, City Manager
OF INTEREST
The Calhoun County Board of County Commissioners will receive Letters of Interest from any qualified engineering and surveying firm interested in providing the requested services for the following project:
ALTHA SIDEWALK
CONSTRUCTION ENGINEERING AND INSPECTION SERVICES
The project will consist of construction engineering and inspection of the sidewalk and minor drainage improvements along Smith Street, Fuqua Circle and North Street within the Town limits of Altha in accordance with FDOT Standards as identified in the County’s Local Agency Participation contract with FDOT.
The Proposer’s Checklist can be obtained at the Emergency Management Office, 20859 Central Avenue East, Room G40 (located in the basement of the Courthouse), Blountstown, Florida. All questions concerning the checklist can be addressed to Angie Smith (850) 674-8075.
Plans and specifications may be viewed or obtained at Preble-Rish, Inc., 20684 Central Ave. East Blountstown, FL 32424, (850) 674-3300. Cost for plans and specifications will be $50 per set and is non-refundable. Checks should be made payable to Preble-Rish, Inc. Questions concerning the plans or specifications should be addressed to Kristin Brown P.E. (850) 674-3300.
This project is federally funded with assistance from the Florida Department of Transportation (FDOT) and the Federal Highway Administration (FHWA). Conflicts of interest will be governed by FDOT Procedure No. 375-030-006 (Restriction on Consultants Eligibility to Compete for Department Contracts).
Letters of interest will be received until 3:00 p.m. Central Standard Time, on Monday, November 5, 2012, at the, Calhoun County Courthouse, Clerk of Court Office, 20859 Central Avenue East, Room 130, Blountstown, Florida.
Please indicate on the envelope that this is a sealed bid, for the “Altha Sidewalk CEI Services”.
Calhoun County is an Equal Opportunity Employer/Handicapped Accessible/Fair Housing Jurisdiction.
Legal Notice
NOTICE TO RECEIVE SEALED BIDS
The Calhoun County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in providing construction services for the following project:
ALTHA SIDEWALK PROJECT
This project will include the construction of 4,265± LF of 6’ wide sidewalk on North Street, Fuqua Circle and Smith Street within the Altha community. Detectable warnings, thermoplastic striping, and minor drainage improvements are also included.
Plans and specifications can be obtained at Preble-Rish, Inc., 20684 Central Avenue East, Blountstown, Florida 32424, (850) 674-3300 (For questions, please call Kristin Brown at (850) 674-3300). The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
Completion date for this project will be 120 days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day.
Please indicate on the envelope that this is a sealed bid, for the “Altha Sidewalk Project”.
Bids will be received until 12:00 p.m. Central Time, on Tuesday, November 13, 2012, at the Calhoun County Courthouse, Clerk’s Office, 20859 Central Avenue East, Room 130, Blountstown, FL 32424, and will be opened and read aloud on Tuesday, November 13, 2012 at 2:00 p.m. CT. Calhoun County Board of Commissioners is an Equal Opportunity Employer/Handicapped Accessible/Fair Housing Jurisdiction.
Cost for Plans and Specifications will be $50.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC.
The Calhoun County Board of Commissioners reserves the right to reject any and all bids. All Bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida.
This project is federally funded with assistance from the Federal Highway Administration and the Florida Department of Transportation.
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT
IN AND FOR
CALHOUN COUNTY, FLORIDA
CASE NO.: 12-244 CA
IN RE: FORFEITURE OF:
2000 Chevrolet Pickup;
VIN #1 GCCS14W7Y8196981
Robert Lee Miller
NOTICE OF FORFEITURE
PROCEEDING
TO ALL PERSONS WHO CLAIM AN INTEREST IN THE ABOVE-DESCRIBED PROPERTY, WHICH WAS SEIZED ON OR ABOUT SEPTEMBER 12, 2012, IN CALHOUN COUNTY, FLORIDA.
Said property is in the custody of the Blountstown Police Department. Any owner entity, bona fide lienholder or person in possession of the property when seized has the right to contest the Forfeiture Complaint by filing a Response with the Circuit Court within 20 days of the publication of this notice, with a copy of the Response sent to Michelle B. Tagert, Attorney for the Blountstown Police Department, 16908 N.E. Pear Street, Blountstown, Florida 32424. A Petition for Final Order of Forfeiture has been filed in the above-styled cause.
MICHELLE B. TAGERT, ESQ
Fla. Bar No. 70836
BTPleadings@gmail.com (Pleadings)
4431 Lafayette Street
Marianna, FL 32446
850-526-3633 (voice)
850-526-2714 (fax)
Counsel for Blountstown Police Dept.
Legal Notice
REQUEST FOR SEALED BIDS FOR
FOR THE REMOVAL & DISPOSAL
OF FUEL TANK
CITY OF BLOUNTSTOWN
The City of Blountstown is requesting sealed bids for the removal and disposal of an above ground gas/diesel fuel storage tank, to include pumps and canopy. Tank capacity is approximately 5,000 gallons gas, 8,000 gallons diesel. Tank and related components were installed in 2009. Tank can be seen at the City Complex located at 17262 NW Angle St., Blountstown, FL 32424. Please contact Emory Pierce, City Manager at epierce@blountstown.org or (850) 674-5488 for additional details.
Sealed bids marked “FUEL TANKS’ must be received by 2:00 P.M. C.S.T., on Tuesday, November 13, 2012 at City Hall, Attention: City Manager, 20591 Central Ave. W., Blountstown, FL 32424. Bids will then be opened and read aloud during the Regular Session of the City Council on Tuesday, November 13, 2012 at 17276 NW Angle Street, Blountstown, Florida 32424. Bid opening will begin at 6:00 P.M., C.S.T. The City reserves the right to accept all or any part of the Bid(s) deemed in the best interest of the City and to reject any or all Bids.
FROM: Emory Pierce, City Manager
Trackbacks
Trackback specific URI for this entry
No Trackbacks