Legal Notices for week of October 11
Legal Notice
NOTICE OF APPLICATION
FOR WATER USE PERMIT
Notice is hereby given that pursuant to Chapter 373, Florida Statutes, the following application for water use permit has been received by the Northwest Florida Water Management District:
Application number I 07350 filed 09/28/2012
Town of Altha, 25586 N. Main Street, P.O. Box 6, Altha, FL 32421
Requesting a maximum withdrawal of 300,000 gallons per day from the Floridan Aquifer System for Public Supply use by an existing facility
General withdrawal location(s) in Calhoun County: T02N, R09W, Sec. 9, 15C
Application number I07352 filed 10/2/2012
William Ralph McDaniel, 2196 El Bethel Church Rd, Grand Ridge, FL 32442
Requesting a maximum withdrawal of 2,160,000 gallons per day from the Floridan Aquifer System for Agricultural Irrigation use by a proposed facility.
General withdrawal location(s) in Calhoun County: T1N, R10W, Sec. 15A
Interested persons may submit written comments/objection or submit a written request for the notice of proposed agency action (NOPAA) regarding the application by writing to: Division of Resource Regulation, Northwest Florida Water Management District, attn.: Terri Peterson, 152 Water Management Drive, Havana, Florida 32333. A NOPAA will be mailed only to persons who have filed such requests. A NOPAA must be requested in order to be advised of further proceedings and any public hearing date. Written comments/objections or NOPAA request must be received by 5:00 p.m. eastern time on October 26, 2012
No further public notice will be provided regarding this application. Publication of this notice constitutes constructive notice of the permit application to all substantially affected persons.
Legal Notice
REQUEST FOR LETTERS
OF INTEREST
The Calhoun County Board of County Commissioners will receive Letters of Interest from any qualified engineering and surveying firm interested in providing the requested services for the following project:
ALTHA SIDEWALK
CONSTRUCTION ENGINEERING
AND INSPECTION SERVICES
The project will consist of construction engineering and inspection of the sidewalk and minor drainage improvements along Smith Street, Fuqua Circle and North Street within the Town limits of Altha in accordance with FDOT Standards as identified in the County’s Local Agency Participation contract with FDOT.
The Proposer’s Checklist can be obtained at the Emergency Management Office, 20859 Central Avenue East, Room G40 (located in the basement of the Courthouse), Blountstown, Florida. All questions concerning the checklist can be addressed to Angie Smith (850) 674-8075.
Plans and specifications may be viewed or obtained at Preble-Rish, Inc., 20684 Central Ave. East Blountstown, FL 32424, (850) 674-3300. Cost for plans and specifications will be $50 per set and is non-refundable. Checks should be made payable to Preble-Rish, Inc. Questions concerning the plans or specifications should be addressed to Kristin Brown P.E. (850) 674-3300.
This project is federally funded with assistance from the Florida Department of Transportation (FDOT) and the Federal Highway Administration (FHWA). Conflicts of interest will be governed by FDOT Procedure No. 375-030-006 (Restriction on Consultants Eligibility to Compete for Department Contracts).
Letters of interest will be received until 3:00 p.m. Central Standard Time, on Monday, November 5, 2012, at the, Calhoun County Courthouse, Clerk of Court Office, 20859 Central Avenue East, Room 130, Blountstown, Florida.
Please indicate on the envelope that this is a sealed bid, for the “Altha Sidewalk CEI Services”.
Calhoun County is an Equal Opportunity Employer/Handicapped Accessible/Fair Housing Jurisdiction.
Legal Notice
NOTICE TO RECEIVE SEALED BIDS
The Calhoun County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in providing construction services for the following project:
ALTHA SIDEWALK PROJECT
This project will include the construction of 4,265± LF of 6’ wide sidewalk on North Street, Fuqua Circle and Smith Street within the Altha community. Detectable warnings, thermoplastic striping, and minor drainage improvements are also included.
Plans and specifications can be obtained at Preble-Rish, Inc., 20684 Central Avenue East, Blountstown, Florida 32424, (850) 674-3300 (For questions, please call Kristin Brown at (850) 674-3300). The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
Completion date for this project will be 120 days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day.
Please indicate on the envelope that this is a sealed bid, for the “Altha Sidewalk Project”.
Bids will be received until 12:00 p.m. Central Time, on Tuesday, November 13, 2012, at the Calhoun County Courthouse, Clerk’s Office, 20859 Central Avenue East, Room 130, Blountstown, FL 32424, and will be opened and read aloud on Tuesday, November 13, 2012 at 2:00 p.m. CT. Calhoun County Board of Commissioners is an Equal Opportunity Employer/Handicapped Accessible/Fair Housing Jurisdiction.
Cost for Plans and Specifications will be $50.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC.
The Calhoun County Board of Commissioners reserves the right to reject any and all bids. All Bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida.
This project is federally funded with assistance from the Federal Highway Administration and the Florida Department of Transportation.
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT
IN AND FOR
CALHOUN COUNTY, FLORIDA
CIVIL ACTION
CASE NO. 07-2010-CA-000249
BAC HOME LOANS SERVICING, LP FKA
COUNTRYWIDE HOME LOANS SERVICING LP,
Plaintiff,
-vs-
HENRY W. ABBOTT, et al.,
Defendant(s).
NOTICE OF FORECLOSURE SALE
NOTICE IS HEREBY GIVEN pursuant to a Final Judgment of Mortgage Foreclosure dated August 16, 2012 and entered in Case No. 07-2010-CA-000249 of the Circuit Court of the FOURTEENTH Judicial Circuit in and for CALHOUN County, Florida wherein BAC HOME LOANS SERVICING, LP FKA COUNTRYWIDE HOME LOANS SERVICING LP is the Plaintiff and HENRY W. ABBOTT; MARY F. ABBOTT; GEORGE W. BARKER; CHERYL A. BARKER; TENANT #1 N/K/A LINDA ABBOTT are the Defendants, The Clerk of the Court will sell to the highest and best bidder for cash at the LOBBY OF THE CALHOUN COUNTY COURTHOUSE, 20859 E. Central Ave., Blountstown, FL. 32424 at 11:00 a.m. CT, on the 24th day of January, 2013, the following described property as set forth in said Final Judgment:
COMMENCE AT A RAILROAD IRON MARKING THE NORTHWEST CORNER OF THE NORTHWEST 1/4 OF THE SOUTHEAST 1/4 OF SECTION 32, TOWNSHIP 1 NORTH, RANGE 9 WEST, CALHOUN COUNTY, FLORIDA, THENCE RUN NORTH 00 DEGREES 36 MINUTES 13 SECONDS EAST, 990.20 FEET TO A POINT OF THE CENTERLINE OF A PROPOSED 50 FOOT ROADWAY, RUNNING IN AN EASTERLY AND WESTERLY DIRECTION FOR A POINT OF BEGINNING. FROM SAID POINT OF BEGINNING, THENCE RUN SOUTH 89 DEGREES 26 MINUTES 00 SECONDS WEST ALONG SAID CENTERLINE 453.97 FEET TO THE INTERSECTION OF THE CENTERLINE OF A PROPOSED 50 FOOT ROADWAY RUNNING IN A NORTHERLY AND SOUTHERLY DIRECTION; THENCE RUN SOUTH 02 DEGREES 26 MINUTES 00 SECONDS WEST 47.05 FEET, TO A POINT OF A CURVE TO THE RIGHT; THENCE RUN SOUTHWESTERLY ALONE SAID CURVE AND ALONG SAID CENTERLINE WITH A RADIUS OF 174.96 FEET THROUGH A CENTRAL ANGLE OF 34 DEGREES 45 MINUTES 16 SECONDS FOR AN ARC DISTANCE OF 106.13 FEET. THENCE RUN SOUTH 52 DEGREES 48 MINUTES 43 SECONDS EAST 25.0 FEET, TO A IRON PIPE LOCATED ON THE SOUTHEASTERLY RIGHT-OF-WAY BOUNDARY OF SAID PROPOSED 50 FOOT ROADWAY RUNNING IN A NORTHERLY AND SOUTHERLY DIRECTION; THENCE CONTINUE SOUTH 52 DEGREES 48 MINUTES 43 SECONDS EAST 236.30 FEET, TO AN IRON PIPE; THENCE RUN NORTH 89 DEGREES 26 MINUTES 00 SECONDS EAST 280.0 FEET, TO AN IRON PIPE, THENCE RUN NORTH 00 DEGREES 36 MINUTES 13 SECONDS EAST 280.0 FEET, TO AN IRON PIPE LOCATED ON THE SOUTHERLY RIGHT-OF-WAY BOUNDARY OF SAID PROPOSED 50 FOOT ROADWAY RUNNING IN AN EASTERLY AND WESTERLY DIRECTION; THENCE CONTINUE NORTH 00 DEGREES 36 MINUTES 13 SECONDS EAST 25.0 FEET, TO A POINT OF BEGINNING. BEING LOT 47. OF AN UNRECORDED PLAT PREPARED SEPTEMBER 25, 1973, BY APALACHEE ENGINEERS AND LAND SURVEYORS, INC. TALLAHASSEE, FLORIDA.
A/K/A 17239 NW CHIPOLA HEIGHTS ROAD, ALTHA, FL 32421
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the Lis pendens must file a claim within sixty (60) days after the sale.
WITNESS MY HAND and the sale of this Court on September 4, 2012.
Ruth W. Attaway
Clerk of the Circuit Court
FOR WATER USE PERMIT
Notice is hereby given that pursuant to Chapter 373, Florida Statutes, the following application for water use permit has been received by the Northwest Florida Water Management District:
Application number I 07350 filed 09/28/2012
Town of Altha, 25586 N. Main Street, P.O. Box 6, Altha, FL 32421
Requesting a maximum withdrawal of 300,000 gallons per day from the Floridan Aquifer System for Public Supply use by an existing facility
General withdrawal location(s) in Calhoun County: T02N, R09W, Sec. 9, 15C
Application number I07352 filed 10/2/2012
William Ralph McDaniel, 2196 El Bethel Church Rd, Grand Ridge, FL 32442
Requesting a maximum withdrawal of 2,160,000 gallons per day from the Floridan Aquifer System for Agricultural Irrigation use by a proposed facility.
General withdrawal location(s) in Calhoun County: T1N, R10W, Sec. 15A
Interested persons may submit written comments/objection or submit a written request for the notice of proposed agency action (NOPAA) regarding the application by writing to: Division of Resource Regulation, Northwest Florida Water Management District, attn.: Terri Peterson, 152 Water Management Drive, Havana, Florida 32333. A NOPAA will be mailed only to persons who have filed such requests. A NOPAA must be requested in order to be advised of further proceedings and any public hearing date. Written comments/objections or NOPAA request must be received by 5:00 p.m. eastern time on October 26, 2012
No further public notice will be provided regarding this application. Publication of this notice constitutes constructive notice of the permit application to all substantially affected persons.
Legal Notice
REQUEST FOR LETTERS
OF INTEREST
The Calhoun County Board of County Commissioners will receive Letters of Interest from any qualified engineering and surveying firm interested in providing the requested services for the following project:
ALTHA SIDEWALK
CONSTRUCTION ENGINEERING
AND INSPECTION SERVICES
The project will consist of construction engineering and inspection of the sidewalk and minor drainage improvements along Smith Street, Fuqua Circle and North Street within the Town limits of Altha in accordance with FDOT Standards as identified in the County’s Local Agency Participation contract with FDOT.
The Proposer’s Checklist can be obtained at the Emergency Management Office, 20859 Central Avenue East, Room G40 (located in the basement of the Courthouse), Blountstown, Florida. All questions concerning the checklist can be addressed to Angie Smith (850) 674-8075.
Plans and specifications may be viewed or obtained at Preble-Rish, Inc., 20684 Central Ave. East Blountstown, FL 32424, (850) 674-3300. Cost for plans and specifications will be $50 per set and is non-refundable. Checks should be made payable to Preble-Rish, Inc. Questions concerning the plans or specifications should be addressed to Kristin Brown P.E. (850) 674-3300.
This project is federally funded with assistance from the Florida Department of Transportation (FDOT) and the Federal Highway Administration (FHWA). Conflicts of interest will be governed by FDOT Procedure No. 375-030-006 (Restriction on Consultants Eligibility to Compete for Department Contracts).
Letters of interest will be received until 3:00 p.m. Central Standard Time, on Monday, November 5, 2012, at the, Calhoun County Courthouse, Clerk of Court Office, 20859 Central Avenue East, Room 130, Blountstown, Florida.
Please indicate on the envelope that this is a sealed bid, for the “Altha Sidewalk CEI Services”.
Calhoun County is an Equal Opportunity Employer/Handicapped Accessible/Fair Housing Jurisdiction.
Legal Notice
NOTICE TO RECEIVE SEALED BIDS
The Calhoun County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in providing construction services for the following project:
ALTHA SIDEWALK PROJECT
This project will include the construction of 4,265± LF of 6’ wide sidewalk on North Street, Fuqua Circle and Smith Street within the Altha community. Detectable warnings, thermoplastic striping, and minor drainage improvements are also included.
Plans and specifications can be obtained at Preble-Rish, Inc., 20684 Central Avenue East, Blountstown, Florida 32424, (850) 674-3300 (For questions, please call Kristin Brown at (850) 674-3300). The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
Completion date for this project will be 120 days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day.
Please indicate on the envelope that this is a sealed bid, for the “Altha Sidewalk Project”.
Bids will be received until 12:00 p.m. Central Time, on Tuesday, November 13, 2012, at the Calhoun County Courthouse, Clerk’s Office, 20859 Central Avenue East, Room 130, Blountstown, FL 32424, and will be opened and read aloud on Tuesday, November 13, 2012 at 2:00 p.m. CT. Calhoun County Board of Commissioners is an Equal Opportunity Employer/Handicapped Accessible/Fair Housing Jurisdiction.
Cost for Plans and Specifications will be $50.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC.
The Calhoun County Board of Commissioners reserves the right to reject any and all bids. All Bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida.
This project is federally funded with assistance from the Federal Highway Administration and the Florida Department of Transportation.
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT
IN AND FOR
CALHOUN COUNTY, FLORIDA
CIVIL ACTION
CASE NO. 07-2010-CA-000249
BAC HOME LOANS SERVICING, LP FKA
COUNTRYWIDE HOME LOANS SERVICING LP,
Plaintiff,
-vs-
HENRY W. ABBOTT, et al.,
Defendant(s).
NOTICE OF FORECLOSURE SALE
NOTICE IS HEREBY GIVEN pursuant to a Final Judgment of Mortgage Foreclosure dated August 16, 2012 and entered in Case No. 07-2010-CA-000249 of the Circuit Court of the FOURTEENTH Judicial Circuit in and for CALHOUN County, Florida wherein BAC HOME LOANS SERVICING, LP FKA COUNTRYWIDE HOME LOANS SERVICING LP is the Plaintiff and HENRY W. ABBOTT; MARY F. ABBOTT; GEORGE W. BARKER; CHERYL A. BARKER; TENANT #1 N/K/A LINDA ABBOTT are the Defendants, The Clerk of the Court will sell to the highest and best bidder for cash at the LOBBY OF THE CALHOUN COUNTY COURTHOUSE, 20859 E. Central Ave., Blountstown, FL. 32424 at 11:00 a.m. CT, on the 24th day of January, 2013, the following described property as set forth in said Final Judgment:
COMMENCE AT A RAILROAD IRON MARKING THE NORTHWEST CORNER OF THE NORTHWEST 1/4 OF THE SOUTHEAST 1/4 OF SECTION 32, TOWNSHIP 1 NORTH, RANGE 9 WEST, CALHOUN COUNTY, FLORIDA, THENCE RUN NORTH 00 DEGREES 36 MINUTES 13 SECONDS EAST, 990.20 FEET TO A POINT OF THE CENTERLINE OF A PROPOSED 50 FOOT ROADWAY, RUNNING IN AN EASTERLY AND WESTERLY DIRECTION FOR A POINT OF BEGINNING. FROM SAID POINT OF BEGINNING, THENCE RUN SOUTH 89 DEGREES 26 MINUTES 00 SECONDS WEST ALONG SAID CENTERLINE 453.97 FEET TO THE INTERSECTION OF THE CENTERLINE OF A PROPOSED 50 FOOT ROADWAY RUNNING IN A NORTHERLY AND SOUTHERLY DIRECTION; THENCE RUN SOUTH 02 DEGREES 26 MINUTES 00 SECONDS WEST 47.05 FEET, TO A POINT OF A CURVE TO THE RIGHT; THENCE RUN SOUTHWESTERLY ALONE SAID CURVE AND ALONG SAID CENTERLINE WITH A RADIUS OF 174.96 FEET THROUGH A CENTRAL ANGLE OF 34 DEGREES 45 MINUTES 16 SECONDS FOR AN ARC DISTANCE OF 106.13 FEET. THENCE RUN SOUTH 52 DEGREES 48 MINUTES 43 SECONDS EAST 25.0 FEET, TO A IRON PIPE LOCATED ON THE SOUTHEASTERLY RIGHT-OF-WAY BOUNDARY OF SAID PROPOSED 50 FOOT ROADWAY RUNNING IN A NORTHERLY AND SOUTHERLY DIRECTION; THENCE CONTINUE SOUTH 52 DEGREES 48 MINUTES 43 SECONDS EAST 236.30 FEET, TO AN IRON PIPE; THENCE RUN NORTH 89 DEGREES 26 MINUTES 00 SECONDS EAST 280.0 FEET, TO AN IRON PIPE, THENCE RUN NORTH 00 DEGREES 36 MINUTES 13 SECONDS EAST 280.0 FEET, TO AN IRON PIPE LOCATED ON THE SOUTHERLY RIGHT-OF-WAY BOUNDARY OF SAID PROPOSED 50 FOOT ROADWAY RUNNING IN AN EASTERLY AND WESTERLY DIRECTION; THENCE CONTINUE NORTH 00 DEGREES 36 MINUTES 13 SECONDS EAST 25.0 FEET, TO A POINT OF BEGINNING. BEING LOT 47. OF AN UNRECORDED PLAT PREPARED SEPTEMBER 25, 1973, BY APALACHEE ENGINEERS AND LAND SURVEYORS, INC. TALLAHASSEE, FLORIDA.
A/K/A 17239 NW CHIPOLA HEIGHTS ROAD, ALTHA, FL 32421
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the Lis pendens must file a claim within sixty (60) days after the sale.
WITNESS MY HAND and the sale of this Court on September 4, 2012.
Ruth W. Attaway
Clerk of the Circuit Court
Trackbacks
Trackback specific URI for this entry
No Trackbacks