Legal Notice
Legals for 09-15-11
ADVERTISEMENT FOR BIDS
THE CITY OF
BLOUNTSTOWN, FLORIDA
ELECTRIC DISTRIBUTION
SYSTEM UPGRADES
Bid No. 2011-02
Sealed proposals for furnishing all plant, labor, materials and equipment and constructing the ELECTRIC DISTRIBUTION SYSTEM UPGRADES, for the City of Blountstown, Florida, will be received at City Hall, Attention: Mr. Emory Pierce, City Manager, 20591 Central Avenue West, Blountstown, Florida, 32424, or hand delivered to the office listed above, until 2:00 P.M. local time Tuesday, October 11, 2011. The bids will be opened, and publicly read aloud at 6:00 P.M. local time at 17262 NW Angle Street, Blountstown, Florida, 32424, during the City Council meeting. Bids received after the above time and date will be returned unopened.
PROJECT DESCRIPTION:
The project includes the following work:
• Two miles of 477 kcmil ACSR 12.5/7.2 kV new feeder
• 1.75 miles of 1/0 AWG ACSR 12.5/7.2 kV reconductoring
• Reconfigure existing delivery point to add regulators and overall capacity
• Safety repairs, pole inspection and treatment and wood pole replacement throughout the City
There will be a mandatory pre-bid meeting for the project at 10:00 A.M. on Thursday, September 22, 2011. The meeting will be held at 17262 NW Angle Street, Blountstown, Florida, 32424.
Plans, Specifications, and Contract Documents are open to public inspection at the City of Blountstown City Hall, 20591 Central Ave. West, Blountstown, FL 32424. A non-refundable fee of $60.00 will be charged for each set of documents requested.
Questions regarding Plans and Specifications should be directed to Mr. R.L. Willoughby, PowerServices, Inc. at (919) 256-5900 or Mr. Travis Justice, Preble-Rish, Inc. at (850) 522-0644. Questions regarding Procurement or Grant Funding should be directed to Traci Hall, City of Blountstown at (850) 674-5488. Questions/clarifications submitted after Wednesday, October 5, 2011, will not be accepted.
Each bid must be accompanied by a certified check or bid bond by an acceptable surety company of not less than ten percent (10%) of the amount of the bid, made payable to The City of Blountstown, Florida, as a bid guarantee.
A Performance and a Payment Bond will be required for the successful Bidder in the amount of one hundred percent (100%) of the contract price, conditioned upon the faithful performance of the contract, payment of all persons supplying labor or furnishing materials, and payment of all liabilities incurred in connection with the work under this contract.
No bid may be withdrawn for a period of one hundred and eighty days (180) days after scheduled closing time for receiving bids.
The Owner reserves the right to reject any or all bids, or any portion of any bid, and the award, if award is made, will be made to the lowest responsible bidder whose qualifications indicate the award will be in the best interest of the Owner and whose proposal complies with all the prescribed requirements. The Owner reserves the right to waive formalities and technicalities in the bidding procedure.
No consideration will be given any request for Plans and Specifications within the five (5) day period immediately prior to the date for receiving bids.
Bids must be submitted on the printed form, or exact copies thereof, contained in the Contract Documents.
Bids must be submitted in sealed envelopes marked “Bid for ELECTRIC DISTRIBUTION SYSTEM UPGRADES.” In addition, the bidder’s name and address shall be shown on the outside of the sealed envelope. If submitted by mail, the sealed envelope shall be enclosed in a separate mailing envelope.
CITY OF BLOUNTSTOWN
CALHOUN COUNTY, FLORIDA
By/s/ Emory Pierce
City Manager
Legal Notice
NOTICE OF APPLICATION
FOR WATER USE PERMIT
Notice is hereby given that pursuant to Chapter 373, Florida Statutes, the following application(s) for water use permit(s) has (have) been received by the Northwest Florida Water Management District:
Application number I 07234 filed 08/30/2011
Mark Daryl Peacock, 27513 S.R. 71N, Altha, FL 32421
Requesting a maximum withdrawal of 978,000 gallons per day from the Floridan Aquifer and May Mill Creek for Agricultural Irrigation use by an existing facility.
General withdrawal location(s) in Calhoun County: T02N, R09W, Sec. 3; T2N, R9W, Sec. 3.
Interested persons may object to or comment upon the applications or submit a written request for a copy of the staff report(s) containing proposed agency action regarding the application(s) by writing to the Division of Resource Regulation of the Northwest Florida Water Management District, attention Terri Peterson, 152 Water Management Drive, Havana, Florida 32333-9700, but such comments or requests must be received by 5 o’clock p.m. on September 28, 2011.
No further public notice will be provided regarding this (these) application(s). Publication of this notice constitutes constructive notice of this permit application to all substantially affected persons. A copy of the staff report(s) must be requested in order to remain advised of further proceedings and any public hearing date. Substantially affected persons are entitled to request an administrative hearing regarding the proposed agency action by submitting a written request according to the provisions of 28-106.201, Florida Administrative Code. Notices of Proposed Agency Action will be mailed only to persons who have filed such requests.
Legal Notice
PUBLIC AUCTION
Paul’s Wrecker Service will hold a public auction on October 10, 2011 at 10:00 a.m. (C.T.).
2001 Ford Taurus SE
Vin# 1FAFP53U61A191345
Green in color
Auction will be held at Paul’s Wrecker Service, 19844 S.W. South Street, Suite A, Blountstown, Florida.
Paul’s Wrecker Service reserves the right to reject any and all bids. PH: 850-674-TOWS (8697)
Legal Notice
PUBLIC AUCTION
Paul’s Wrecker Service will hold a public auction on September 28, 2011 at 10:00 a.m. (C.T.).
2007 Toyota Camry
Vin #4T1BE46K57U714909
White in color
Auction will be held at Paul’s Wrecker Service, 19844 S.W. South Street, Suite A, Blountstown, Florida.
Paul’s Wrecker Service reserves the right to reject any and all bids. PH: 850-674-TOWS (8697)
Legal Notice
PUBLIC AUCTION
Paul’s Wrecker Service will hold a public auction on October 10, 2011 at 10:00 a.m. (C.T.).
1998 Dodge Dakota Pick Up
Vin# 1B7FL26P1WS518522
Green and Black in color
Auction will be held at Paul’s Wrecker Service, 19844 S.W. South Street, Suite A, Blountstown, Florida.
Paul’s Wrecker Service reserves the right to reject any and all bids. PH: 850-674-TOWS (8697)
Legal Notice
CALHOUN COUNTY 2010-2011 FEMA REPAIRS, GROUP 5
NOTICE TO RECEIVE SEALED BIDS
The Calhoun County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing:
CALHOUN COUNTY 2010-2011
FEMA REPAIRS, GROUP 5
Plans and specifications can be obtained at Preble-Rish, Inc., 20684 Central Avenue East, Blountstown, FL 32424, (850) 674-3300. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
MCCLELLAN FARM ROAD - DR 1785 PW 1635/5-12
CLAYTON SHIVER ROAD - DR 1785
PW 1576/5-13
SW SEGERS ROAD - DR 1831
PW 717/5-36
This project is a roadway construction project, which consists of grading, shaping, compacting limerock base, reworking shoulders, ditch cleaning and shaping.
All bidders shall be pre-qualified with the Florida Department of Transportation per Section 2-1 of the F.D.O.T. Standard Specifications for Road and Bridge Construction, 2010 edition for:
FLEXIBLE PAVING
Completion date for these projects will be 180 days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day.
Please indicate on the envelope that this is a sealed bid, the bid number and what the bid is for.
Bids will be received until 2:00 p.m. (C.T.), on Tuesday, September 20 , 20 11 , at the Calhoun County Clerk's Office, Calhoun County Courthouse, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424, and will be opened and read aloud on Tuesday, September 20, 2011 at 5:00 p.m. (C.T.)
Cost for Plans and Specifications will be $75.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC.
The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Calhoun County.
If you have any questions, please call Donald Stanley at (850) 674-3300 or stanleyd@preble-rish.com.
Legal Notice
CALHOUN COUNTY 2010-2011 FEMA REPAIRS, GROUP 6
NOTICE TO RECEIVE SEALED BIDS
The Calhoun County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing:
CALHOUN COUNTY 2010-2011
FEMA REPAIRS, GROUP 6
Plans and specifications can be obtained at Preble-Rish, Inc., 20684 Central Avenue East, Blountstown, FL 32424, (850) 674-3300. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
SMITH TOWER - DR 1831 PW 553/5-30
COUNTY ROAD 8 - DR 1831
PW 530/5-28
COUNTY ROAD 19 - DR 1785
PW 1865/5-10
This project is a roadway construction project, which consists of grading, shaping, compacting limerock base, reworking shoulders, ditch cleaning and shaping.
All bidders shall be pre-qualified with the Florida Department of Transportation Section 2-1 of the F.D.O.T. Standard Specifications for Road and Bridge Construction, 2010 edition for:
FLEXIBLE PAVING
Completion date for these projects will be 180 days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day.
Please indicate on the envelope that this is a sealed bid, the bid number and what the bid is for.
Bids will be received until 2:00 p.m. (C.T.), on Tuesday, September 20, 20 11, at the Calhoun County Clerk's Office, Calhoun County Courthouse, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424, and will be opened and read aloud on Tuesday, September 20, 2011 at 5:00 p.m. (C.T.)
Cost for Plans and Specifications will be $75.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC.
The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Calhoun County.
If you have any questions, please call Donald Stanley at (850) 674-3300 or
stanleyd@preble-rish.com.
THE CITY OF
BLOUNTSTOWN, FLORIDA
ELECTRIC DISTRIBUTION
SYSTEM UPGRADES
Bid No. 2011-02
Sealed proposals for furnishing all plant, labor, materials and equipment and constructing the ELECTRIC DISTRIBUTION SYSTEM UPGRADES, for the City of Blountstown, Florida, will be received at City Hall, Attention: Mr. Emory Pierce, City Manager, 20591 Central Avenue West, Blountstown, Florida, 32424, or hand delivered to the office listed above, until 2:00 P.M. local time Tuesday, October 11, 2011. The bids will be opened, and publicly read aloud at 6:00 P.M. local time at 17262 NW Angle Street, Blountstown, Florida, 32424, during the City Council meeting. Bids received after the above time and date will be returned unopened.
PROJECT DESCRIPTION:
The project includes the following work:
• Two miles of 477 kcmil ACSR 12.5/7.2 kV new feeder
• 1.75 miles of 1/0 AWG ACSR 12.5/7.2 kV reconductoring
• Reconfigure existing delivery point to add regulators and overall capacity
• Safety repairs, pole inspection and treatment and wood pole replacement throughout the City
There will be a mandatory pre-bid meeting for the project at 10:00 A.M. on Thursday, September 22, 2011. The meeting will be held at 17262 NW Angle Street, Blountstown, Florida, 32424.
Plans, Specifications, and Contract Documents are open to public inspection at the City of Blountstown City Hall, 20591 Central Ave. West, Blountstown, FL 32424. A non-refundable fee of $60.00 will be charged for each set of documents requested.
Questions regarding Plans and Specifications should be directed to Mr. R.L. Willoughby, PowerServices, Inc. at (919) 256-5900 or Mr. Travis Justice, Preble-Rish, Inc. at (850) 522-0644. Questions regarding Procurement or Grant Funding should be directed to Traci Hall, City of Blountstown at (850) 674-5488. Questions/clarifications submitted after Wednesday, October 5, 2011, will not be accepted.
Each bid must be accompanied by a certified check or bid bond by an acceptable surety company of not less than ten percent (10%) of the amount of the bid, made payable to The City of Blountstown, Florida, as a bid guarantee.
A Performance and a Payment Bond will be required for the successful Bidder in the amount of one hundred percent (100%) of the contract price, conditioned upon the faithful performance of the contract, payment of all persons supplying labor or furnishing materials, and payment of all liabilities incurred in connection with the work under this contract.
No bid may be withdrawn for a period of one hundred and eighty days (180) days after scheduled closing time for receiving bids.
The Owner reserves the right to reject any or all bids, or any portion of any bid, and the award, if award is made, will be made to the lowest responsible bidder whose qualifications indicate the award will be in the best interest of the Owner and whose proposal complies with all the prescribed requirements. The Owner reserves the right to waive formalities and technicalities in the bidding procedure.
No consideration will be given any request for Plans and Specifications within the five (5) day period immediately prior to the date for receiving bids.
Bids must be submitted on the printed form, or exact copies thereof, contained in the Contract Documents.
Bids must be submitted in sealed envelopes marked “Bid for ELECTRIC DISTRIBUTION SYSTEM UPGRADES.” In addition, the bidder’s name and address shall be shown on the outside of the sealed envelope. If submitted by mail, the sealed envelope shall be enclosed in a separate mailing envelope.
CITY OF BLOUNTSTOWN
CALHOUN COUNTY, FLORIDA
By/s/ Emory Pierce
City Manager
Legal Notice
NOTICE OF APPLICATION
FOR WATER USE PERMIT
Notice is hereby given that pursuant to Chapter 373, Florida Statutes, the following application(s) for water use permit(s) has (have) been received by the Northwest Florida Water Management District:
Application number I 07234 filed 08/30/2011
Mark Daryl Peacock, 27513 S.R. 71N, Altha, FL 32421
Requesting a maximum withdrawal of 978,000 gallons per day from the Floridan Aquifer and May Mill Creek for Agricultural Irrigation use by an existing facility.
General withdrawal location(s) in Calhoun County: T02N, R09W, Sec. 3; T2N, R9W, Sec. 3.
Interested persons may object to or comment upon the applications or submit a written request for a copy of the staff report(s) containing proposed agency action regarding the application(s) by writing to the Division of Resource Regulation of the Northwest Florida Water Management District, attention Terri Peterson, 152 Water Management Drive, Havana, Florida 32333-9700, but such comments or requests must be received by 5 o’clock p.m. on September 28, 2011.
No further public notice will be provided regarding this (these) application(s). Publication of this notice constitutes constructive notice of this permit application to all substantially affected persons. A copy of the staff report(s) must be requested in order to remain advised of further proceedings and any public hearing date. Substantially affected persons are entitled to request an administrative hearing regarding the proposed agency action by submitting a written request according to the provisions of 28-106.201, Florida Administrative Code. Notices of Proposed Agency Action will be mailed only to persons who have filed such requests.
Legal Notice
PUBLIC AUCTION
Paul’s Wrecker Service will hold a public auction on October 10, 2011 at 10:00 a.m. (C.T.).
2001 Ford Taurus SE
Vin# 1FAFP53U61A191345
Green in color
Auction will be held at Paul’s Wrecker Service, 19844 S.W. South Street, Suite A, Blountstown, Florida.
Paul’s Wrecker Service reserves the right to reject any and all bids. PH: 850-674-TOWS (8697)
Legal Notice
PUBLIC AUCTION
Paul’s Wrecker Service will hold a public auction on September 28, 2011 at 10:00 a.m. (C.T.).
2007 Toyota Camry
Vin #4T1BE46K57U714909
White in color
Auction will be held at Paul’s Wrecker Service, 19844 S.W. South Street, Suite A, Blountstown, Florida.
Paul’s Wrecker Service reserves the right to reject any and all bids. PH: 850-674-TOWS (8697)
Legal Notice
PUBLIC AUCTION
Paul’s Wrecker Service will hold a public auction on October 10, 2011 at 10:00 a.m. (C.T.).
1998 Dodge Dakota Pick Up
Vin# 1B7FL26P1WS518522
Green and Black in color
Auction will be held at Paul’s Wrecker Service, 19844 S.W. South Street, Suite A, Blountstown, Florida.
Paul’s Wrecker Service reserves the right to reject any and all bids. PH: 850-674-TOWS (8697)
Legal Notice
CALHOUN COUNTY 2010-2011 FEMA REPAIRS, GROUP 5
NOTICE TO RECEIVE SEALED BIDS
The Calhoun County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing:
CALHOUN COUNTY 2010-2011
FEMA REPAIRS, GROUP 5
Plans and specifications can be obtained at Preble-Rish, Inc., 20684 Central Avenue East, Blountstown, FL 32424, (850) 674-3300. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
MCCLELLAN FARM ROAD - DR 1785 PW 1635/5-12
CLAYTON SHIVER ROAD - DR 1785
PW 1576/5-13
SW SEGERS ROAD - DR 1831
PW 717/5-36
This project is a roadway construction project, which consists of grading, shaping, compacting limerock base, reworking shoulders, ditch cleaning and shaping.
All bidders shall be pre-qualified with the Florida Department of Transportation per Section 2-1 of the F.D.O.T. Standard Specifications for Road and Bridge Construction, 2010 edition for:
FLEXIBLE PAVING
Completion date for these projects will be 180 days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day.
Please indicate on the envelope that this is a sealed bid, the bid number and what the bid is for.
Bids will be received until 2:00 p.m. (C.T.), on Tuesday, September 20 , 20 11 , at the Calhoun County Clerk's Office, Calhoun County Courthouse, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424, and will be opened and read aloud on Tuesday, September 20, 2011 at 5:00 p.m. (C.T.)
Cost for Plans and Specifications will be $75.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC.
The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Calhoun County.
If you have any questions, please call Donald Stanley at (850) 674-3300 or stanleyd@preble-rish.com.
Legal Notice
CALHOUN COUNTY 2010-2011 FEMA REPAIRS, GROUP 6
NOTICE TO RECEIVE SEALED BIDS
The Calhoun County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing:
CALHOUN COUNTY 2010-2011
FEMA REPAIRS, GROUP 6
Plans and specifications can be obtained at Preble-Rish, Inc., 20684 Central Avenue East, Blountstown, FL 32424, (850) 674-3300. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
SMITH TOWER - DR 1831 PW 553/5-30
COUNTY ROAD 8 - DR 1831
PW 530/5-28
COUNTY ROAD 19 - DR 1785
PW 1865/5-10
This project is a roadway construction project, which consists of grading, shaping, compacting limerock base, reworking shoulders, ditch cleaning and shaping.
All bidders shall be pre-qualified with the Florida Department of Transportation Section 2-1 of the F.D.O.T. Standard Specifications for Road and Bridge Construction, 2010 edition for:
FLEXIBLE PAVING
Completion date for these projects will be 180 days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day.
Please indicate on the envelope that this is a sealed bid, the bid number and what the bid is for.
Bids will be received until 2:00 p.m. (C.T.), on Tuesday, September 20, 20 11, at the Calhoun County Clerk's Office, Calhoun County Courthouse, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424, and will be opened and read aloud on Tuesday, September 20, 2011 at 5:00 p.m. (C.T.)
Cost for Plans and Specifications will be $75.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC.
The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Calhoun County.
If you have any questions, please call Donald Stanley at (850) 674-3300 or
stanleyd@preble-rish.com.
Trackbacks
Trackback specific URI for this entry
No Trackbacks