Legal Notices For 08-13-09
Legal Notices For 08-13-09
Legal Notice
BLOUNTSTOWN TRAIL IMPROVEMENTS PROJECT #013.014
NOTICE TO RECEIVE SEALED BIDS
The City of Blountstown will receive sealed bids from any qualified person, company or corporation interested in providing the requested services for the following project:
BLOUNTSTOWN TRAIL IMPROVEMENTS
The project is located at the Depot Trailhead in Blountstown, Florida. The project improvements will include the construction of a new restroom, pavilion, playground equipment and concrete sidewalk.
Plans and specifications can be obtained at Preble-Rish, Inc., 20684 Central Avenue, East, Blountstown, Florida 32424, (850)674-3300. Cost for plans and specifications will be $ 75.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC.
The substantial completion date for this project will be 60 days from the date of the Notice to Proceed presented to the successful bidder and fully complete with 90 days from the date of the Notice to Proceed.
Liquidated damages for failure to complete the project on the specified date will be set at $250.00 per day.
Please indicate on the envelope that this is a sealed bid, for the “BLOUNTSTOWN TRAIL IMPROVEMENTS”
Bids will be received until _3_p.m. Central Standard Time, on August 25, 2009, at the City of Blountstown City Hall, 20591 Central Avenue West, Blountstown, Florida 32424, and will be opened and read at that time on the same date during their regularly scheduled meeting. The City of Blountstown is an Equal Opportunity Employer/Handicapped Accessible/Fair Housing Jurisdiction.
The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. A Bid Bond in the amount of 5% of the Bid shall accompany the Bid. The City of Blountstown reserves the right to reject any and all bids. All Bids shall remain firm for a period of sixty days after the opening.
All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida.
AD run date: August 5th, 2009
Legal Notice
R & R WAREHOUSES
NOTICE OF SALE
On August 17, 2009, at 10:00 a.m. (CST), R & R Warehouses will dispose of the contents of seven (7) storage units from Blountstown and four (4) storage units from Bristol at 19300 SR 20 W. (850) 674-4700.
The units are believed to contain household and/or personal property of the following tenants:
Jerry Brown
Antonio Charleston
Deidre Daughtrey
Ricky Davis
Tammy Fisher
Marvadean Kirkland
Jackie Lytle
Jacquelyn Mango
Cherlyn Morgan
All units not paid in full by this date will be disposed of. THERE WILL BE NO AUCTION!!
Legal Notice
NOTICE OF POTENTIAL VOTER REGISTRATION INELIGIBILITY
Pursuant to Section 98.075, Florida Statutes, and information provided by the State of Florida Division of Elections, the Calhoun County Supervisor of Elections hereby provides notice that the following individuals are potentially ineligible to be registered to vote in Calhoun County and may be declared ineligible to vote if they fail to contact the Supervisor’s Office within 30 days after the date this notice is published:
Domenique M. Ivory Sr., 20926 SE Azalea Dr., Blountstown, FL 32424
Albert Johnson Jr., 16190 SE Boyd St., Blountstown, FL 32424
Heather M. Tweedy, 19339 SW Hidden Creek Rd., Lot 44, Blountstown, FL 32424
An individual who fails to respond to this notice may also have his or her name removed from the statewide voter registration system. Any individual listed may contact the Supervisor’s Office no later than 30 days after the date this notice is published to receive information regarding the basis for the potential ineligibility and the procedure to resolve the matter. Should a listed individual need further assistance, he or she should contact the Calhoun County Supervisor of Elections Office at (850) 674-8568. Published August 12, 2009, as required by Florida law.
MARGIE C. LARAMORE
CALHOUN COUNTY SUPERVISOR OF ELECTIONS
20859 CENTRAL AVE. EAST, RM. G-10
BLOUNTSTOWN, FL 32424
PHONE (850) 674-8568
Legal Notice
REQUEST FOR PROPOSALS
The Board of County Commissioners (BCC) of Calhoun County, Florida will receive sealed proposals from any qualified person, company, or corporation interested in providing the following services:
SOLID WASTE COLLECTION/DISPOSAL
SERVICES
Proposals will be received until 2:00 p.m. (CT), on Tuesday, September 15 , 2009, at the Calhoun County Clerk’s Office, Calhoun County Courthouse, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424. Proposals will be opened and read aloud at 5:00 p.m. (CT) or as soon as possible thereafter on Tuesday, September 15 , 2009, in the Open Session of BCC. All proposals should be sealed and marked “Calhoun County Solid Waste Collection/Disposal Services Proposal”. Detailed information and proposal forms can be obtained at no charge from the Emergency Management Office at 20859 Central Avenue East, Room G-40, located in the basement of the Calhoun County Courthouse or online at www.calhounflorida.org. For additional information, you may contact Don A. O’Bryan at (850) 674-8075.
A mandatory pre-bid conference will be held on Tuesday, August 25, 2009 at 10:00 a.m. (CT), in the Emergency Operations Center (EOC), located in the basement of the Courthouse.
Each proposal must be accompanied by a Bid Bond or cashier’s check payable to the Calhoun County Board of County Commissioners for five percent (5%) of the required $1,000,000 million dollars Performance Bond.
The Board of County Commissioners reserves the right to waive informalities or to reject any or all proposals. Awards will be made on the basis of the cost and qualification/reputation of the proposer. The Board will not be obligated to award the contract to the lowest proposer.
Legal Notice
IN THE CIRCUIT COURT OF THE
FOURTEENTH JUDICIAL CIRCUIT
IN AND FOR CALHOUN COUNTY, FLORIDA
CIVIC ACTION
CASE NO.: 07-2008-CA-000272
CHASE HOME FINANCE LLC,
Plaintiff,
-vs-
KRISTINA L. SUTHERLAND, et al.,
Defendant(s)
NOTICE OF RESCHEDULED FORECLOSURE SALE
NOTICE IS HEREBY GIVEN pursuant to an Order Rescheduling Foreclosure Sale dated August 5, 2009 and entered in Case No. 07-2008-CA-000272 of the Circuit Court of the FOURTEENTH Judicial Circuit in and for CALHOUN County, Florida where CHASE HOME FINANCE LLC, is the Plaintiff and KRISTINE L. SUTHERLAND; BARBARA L. SUTHERLAND; AND ANY AND ALL UNKNOWN PARTIES CLAIMING BY, THROUGH, UNDER, AND AGAINST THE HEREIN NAMED INDIVIDUAL DEFENDANT(S) WHO ARE NOT KNOWN TO BE DEAD OR ALIVE, WHETHER SAID UNKNOWN PARTIES MAY CLAIM AN INTEREST AS SPOUSE, HEIRS, DEVISEES, GRANTEES, OR OTHER CLAIMANTS; are the Defendants, I will sell to the highest and best bidder for cash at LOBBY OF THE CALHOUN COUNTY COURTHOUSE at 11:00 AM CST, on the 3rd day of September, 2009, the following described property as set forth in said Final Judgment:
COMMENCE AT A 6 INCH SQUARE CONCRETE MONUMENT MARKING THE SOUTHWEST CORNER OF SECTION 35, TOWNSHIP 2 NORTH, RANGE 11 WEST, CALHOUN COUNTY, FLORIDA AND RUN THENCE NORTH 89 DEGREES 22 MINUTES 27 SECONDS WEST ALONG THE SOUTHERLY BOUNDARY OF SAID SECTION 35 A DISTANCE OF 1647.39 FEET TO THE SOUTHEAST CORNER OF THE WEST HALF OF THE SOUTHEAST QUARTER OF THE SOUTHWEST CORNER OF THE SOUTHEAST QUARTER OF SAID SECTION 35 AND THE POINT OF BEGINNING. FROM SAID POINT OF BEGINNING THENCE NORTH 00 DEGREES 28 MINUTES 28 SECONDS WEST 134.97 FEET THENCE NORTH 89 DEGREES 34 MINUTES 05 SECONDS WEST 329.83 FEET THENCE SOUTH 00 DEGREES 38 MINUTES 06 SECONDS EAST 133.86 FEET TO SAID SOUTHERLY BOUNDARY; THENCE SOUTH 89 DEGREES 22 MINUTES 27 SECONDS EAST ALONG SAID SOUTHERLY BOUNDARY A DISTANCE OF 329.48 FEET TO THE POINT OF BEGINNING. WHICH INCLUDES THAT CERTAIN 2007 KING MODEL NO. 44E3H, NOBILITY MANUFACTURED HOME, SERIAL NO. N813072A/N813072B, WHICH IS ATTACHED AND MADE A PART OF THE REAL PROPERTY. WHICH, BY INTENTION OF THE PARTIES AND UPON RETIREMENT OF THE CERTIFICATE OF TITLE AS PROVIDED IN 319.261 FLORIDA, STATUTES, SHALL CONSTITUTE A PART OF THE REALTY AND SHALL PASS WITH IT.
A/K/A 5142 NW MILLER ROAD, ALTHA, FL 324210000
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the Lis pendens must file a claim within sixty (60) days after the sale.
WITNESS MY HAND and the seal of this Court on August 6, 2009.
Ruth W. Attaway
Clerk of the Circuit Court
Legal Notice
PUBLIC AUCTION
Blountstown Collision Center, Inc. will hold a public auction on, September 19, 2009 at 1:00 (P.M.) on A:
2008 Nissan Titan Truck
Vin# 1N6BA07D58N321333
Auction will be held at Mallory Towing and Recovery Inc. at 18925 Hwy. 20 W in Blountstown FL., 850-674-4013
Blountstown Collision Center, Inc. reserves the right to reject any and all bids.
BLOUNTSTOWN TRAIL IMPROVEMENTS PROJECT #013.014
NOTICE TO RECEIVE SEALED BIDS
The City of Blountstown will receive sealed bids from any qualified person, company or corporation interested in providing the requested services for the following project:
BLOUNTSTOWN TRAIL IMPROVEMENTS
The project is located at the Depot Trailhead in Blountstown, Florida. The project improvements will include the construction of a new restroom, pavilion, playground equipment and concrete sidewalk.
Plans and specifications can be obtained at Preble-Rish, Inc., 20684 Central Avenue, East, Blountstown, Florida 32424, (850)674-3300. Cost for plans and specifications will be $ 75.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC.
The substantial completion date for this project will be 60 days from the date of the Notice to Proceed presented to the successful bidder and fully complete with 90 days from the date of the Notice to Proceed.
Liquidated damages for failure to complete the project on the specified date will be set at $250.00 per day.
Please indicate on the envelope that this is a sealed bid, for the “BLOUNTSTOWN TRAIL IMPROVEMENTS”
Bids will be received until _3_p.m. Central Standard Time, on August 25, 2009, at the City of Blountstown City Hall, 20591 Central Avenue West, Blountstown, Florida 32424, and will be opened and read at that time on the same date during their regularly scheduled meeting. The City of Blountstown is an Equal Opportunity Employer/Handicapped Accessible/Fair Housing Jurisdiction.
The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. A Bid Bond in the amount of 5% of the Bid shall accompany the Bid. The City of Blountstown reserves the right to reject any and all bids. All Bids shall remain firm for a period of sixty days after the opening.
All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida.
AD run date: August 5th, 2009
Legal Notice
R & R WAREHOUSES
NOTICE OF SALE
On August 17, 2009, at 10:00 a.m. (CST), R & R Warehouses will dispose of the contents of seven (7) storage units from Blountstown and four (4) storage units from Bristol at 19300 SR 20 W. (850) 674-4700.
The units are believed to contain household and/or personal property of the following tenants:
Jerry Brown
Antonio Charleston
Deidre Daughtrey
Ricky Davis
Tammy Fisher
Marvadean Kirkland
Jackie Lytle
Jacquelyn Mango
Cherlyn Morgan
All units not paid in full by this date will be disposed of. THERE WILL BE NO AUCTION!!
Legal Notice
NOTICE OF POTENTIAL VOTER REGISTRATION INELIGIBILITY
Pursuant to Section 98.075, Florida Statutes, and information provided by the State of Florida Division of Elections, the Calhoun County Supervisor of Elections hereby provides notice that the following individuals are potentially ineligible to be registered to vote in Calhoun County and may be declared ineligible to vote if they fail to contact the Supervisor’s Office within 30 days after the date this notice is published:
Domenique M. Ivory Sr., 20926 SE Azalea Dr., Blountstown, FL 32424
Albert Johnson Jr., 16190 SE Boyd St., Blountstown, FL 32424
Heather M. Tweedy, 19339 SW Hidden Creek Rd., Lot 44, Blountstown, FL 32424
An individual who fails to respond to this notice may also have his or her name removed from the statewide voter registration system. Any individual listed may contact the Supervisor’s Office no later than 30 days after the date this notice is published to receive information regarding the basis for the potential ineligibility and the procedure to resolve the matter. Should a listed individual need further assistance, he or she should contact the Calhoun County Supervisor of Elections Office at (850) 674-8568. Published August 12, 2009, as required by Florida law.
MARGIE C. LARAMORE
CALHOUN COUNTY SUPERVISOR OF ELECTIONS
20859 CENTRAL AVE. EAST, RM. G-10
BLOUNTSTOWN, FL 32424
PHONE (850) 674-8568
Legal Notice
REQUEST FOR PROPOSALS
The Board of County Commissioners (BCC) of Calhoun County, Florida will receive sealed proposals from any qualified person, company, or corporation interested in providing the following services:
SOLID WASTE COLLECTION/DISPOSAL
SERVICES
Proposals will be received until 2:00 p.m. (CT), on Tuesday, September 15 , 2009, at the Calhoun County Clerk’s Office, Calhoun County Courthouse, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424. Proposals will be opened and read aloud at 5:00 p.m. (CT) or as soon as possible thereafter on Tuesday, September 15 , 2009, in the Open Session of BCC. All proposals should be sealed and marked “Calhoun County Solid Waste Collection/Disposal Services Proposal”. Detailed information and proposal forms can be obtained at no charge from the Emergency Management Office at 20859 Central Avenue East, Room G-40, located in the basement of the Calhoun County Courthouse or online at www.calhounflorida.org. For additional information, you may contact Don A. O’Bryan at (850) 674-8075.
A mandatory pre-bid conference will be held on Tuesday, August 25, 2009 at 10:00 a.m. (CT), in the Emergency Operations Center (EOC), located in the basement of the Courthouse.
Each proposal must be accompanied by a Bid Bond or cashier’s check payable to the Calhoun County Board of County Commissioners for five percent (5%) of the required $1,000,000 million dollars Performance Bond.
The Board of County Commissioners reserves the right to waive informalities or to reject any or all proposals. Awards will be made on the basis of the cost and qualification/reputation of the proposer. The Board will not be obligated to award the contract to the lowest proposer.
Legal Notice
IN THE CIRCUIT COURT OF THE
FOURTEENTH JUDICIAL CIRCUIT
IN AND FOR CALHOUN COUNTY, FLORIDA
CIVIC ACTION
CASE NO.: 07-2008-CA-000272
CHASE HOME FINANCE LLC,
Plaintiff,
-vs-
KRISTINA L. SUTHERLAND, et al.,
Defendant(s)
NOTICE OF RESCHEDULED FORECLOSURE SALE
NOTICE IS HEREBY GIVEN pursuant to an Order Rescheduling Foreclosure Sale dated August 5, 2009 and entered in Case No. 07-2008-CA-000272 of the Circuit Court of the FOURTEENTH Judicial Circuit in and for CALHOUN County, Florida where CHASE HOME FINANCE LLC, is the Plaintiff and KRISTINE L. SUTHERLAND; BARBARA L. SUTHERLAND; AND ANY AND ALL UNKNOWN PARTIES CLAIMING BY, THROUGH, UNDER, AND AGAINST THE HEREIN NAMED INDIVIDUAL DEFENDANT(S) WHO ARE NOT KNOWN TO BE DEAD OR ALIVE, WHETHER SAID UNKNOWN PARTIES MAY CLAIM AN INTEREST AS SPOUSE, HEIRS, DEVISEES, GRANTEES, OR OTHER CLAIMANTS; are the Defendants, I will sell to the highest and best bidder for cash at LOBBY OF THE CALHOUN COUNTY COURTHOUSE at 11:00 AM CST, on the 3rd day of September, 2009, the following described property as set forth in said Final Judgment:
COMMENCE AT A 6 INCH SQUARE CONCRETE MONUMENT MARKING THE SOUTHWEST CORNER OF SECTION 35, TOWNSHIP 2 NORTH, RANGE 11 WEST, CALHOUN COUNTY, FLORIDA AND RUN THENCE NORTH 89 DEGREES 22 MINUTES 27 SECONDS WEST ALONG THE SOUTHERLY BOUNDARY OF SAID SECTION 35 A DISTANCE OF 1647.39 FEET TO THE SOUTHEAST CORNER OF THE WEST HALF OF THE SOUTHEAST QUARTER OF THE SOUTHWEST CORNER OF THE SOUTHEAST QUARTER OF SAID SECTION 35 AND THE POINT OF BEGINNING. FROM SAID POINT OF BEGINNING THENCE NORTH 00 DEGREES 28 MINUTES 28 SECONDS WEST 134.97 FEET THENCE NORTH 89 DEGREES 34 MINUTES 05 SECONDS WEST 329.83 FEET THENCE SOUTH 00 DEGREES 38 MINUTES 06 SECONDS EAST 133.86 FEET TO SAID SOUTHERLY BOUNDARY; THENCE SOUTH 89 DEGREES 22 MINUTES 27 SECONDS EAST ALONG SAID SOUTHERLY BOUNDARY A DISTANCE OF 329.48 FEET TO THE POINT OF BEGINNING. WHICH INCLUDES THAT CERTAIN 2007 KING MODEL NO. 44E3H, NOBILITY MANUFACTURED HOME, SERIAL NO. N813072A/N813072B, WHICH IS ATTACHED AND MADE A PART OF THE REAL PROPERTY. WHICH, BY INTENTION OF THE PARTIES AND UPON RETIREMENT OF THE CERTIFICATE OF TITLE AS PROVIDED IN 319.261 FLORIDA, STATUTES, SHALL CONSTITUTE A PART OF THE REALTY AND SHALL PASS WITH IT.
A/K/A 5142 NW MILLER ROAD, ALTHA, FL 324210000
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the Lis pendens must file a claim within sixty (60) days after the sale.
WITNESS MY HAND and the seal of this Court on August 6, 2009.
Ruth W. Attaway
Clerk of the Circuit Court
Legal Notice
PUBLIC AUCTION
Blountstown Collision Center, Inc. will hold a public auction on, September 19, 2009 at 1:00 (P.M.) on A:
2008 Nissan Titan Truck
Vin# 1N6BA07D58N321333
Auction will be held at Mallory Towing and Recovery Inc. at 18925 Hwy. 20 W in Blountstown FL., 850-674-4013
Blountstown Collision Center, Inc. reserves the right to reject any and all bids.
Trackbacks
Trackback specific URI for this entry
No Trackbacks