Legal Notices For 10-15-09
Legal Notices For 10-15-09
Legal Notice
TUPELO AVENUE
PROJECT # 14.092
NOTICE TO RECEIVE SEALED BIDS
The Calhoun County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing:
TUPELO AVENUE
Plans and specifications can be obtained at Preble-Rish, Inc., 324 Marina Drive, Port St. Joe, Florida 32456, (850) 227-7200. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
This project will consist of installing four 72” pipes with concrete end walls, and repairing the asphalt roadway.
All bidders shall be FDOT Qualified per Section 2-1 of the FDOT Standard Specifications for Road and Bridge Construction, latest edition.
Completion date for these projects will be 150 days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day.
Please indicate on the envelope that this is a sealed bid, the bid number and what the bid is for.
Bids will be received until 2:00 p.m. (C.T.), on Tuesday, October 20, 2009, at the Calhoun County Clerk’s Office, Calhoun County Courthouse, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424, and will be opened and read aloud on Tuesday, October 20, 2009 at 5:00 p.m. (C.T.).
Cost for Plans and Specifications will be $50.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC.
The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Calhoun County.
If you have any questions, please call Matt Carpenter at (850) 643-2771 or email carpenterm@preble-rish.com
Legal Notice
IN THE CIRCUIT COURT OF THE 14TH JUDICIAL CIRCUIT, IN AND FOR CALHOUN COUNTY,
FLORIDA GENERAL JURISDICTION DIVISION
CASE NO:2008-CA-000179
CITIMORTGAGE, INC.
PLAINTIFFS,
-vs-
KIWANIS G. NICHOLS JR.; APRIL GW NICHOLS; ANY AND ALL UNKNOWN PARTIES CLAIMING BY, THROUGH, UNDER, AND AGAINST THE HEREIN NAMED INDIVIDUAL DEFENDANT(S) WHO ARE NOT KNOWN TO BE DEAD OR ALIVE, WHETHER SAID UNKNOWN PARTIES MAY CLAIM AN INTEREST AS SPOUSES, HEIRS, DEVISEES, GRANTEES OR OTHER CLAIMANTS; JOHN DOE AND JANE JOE AS UNKNOWN TENANTS IN POSSESSION,
DEFENDANT(S)
NOTICE OF FORECLOSURE SALE
YOU ARE HEREBY NOTIFIED that pursuant to a Summary Final Judgment of Foreclosure dated September 30, 2009 entered in Civil Case No. 2008-CA-000179 of the Circuit Court of the 14TH Judicial Circuit in and for CALHOUN County, Blountstown, Florida, I will sell to the highest and best bidder for cash at ON THE FRONT STEPS OF THE COURTHOUSE at the CALHOUN County Courthouse located at 20859 SE Central Avenue East in Blountstown, Florida, at 11:00 a.m. CST, on the 29th day of October, 2009 the following described property as set forth in said Summary Final Judgment to-wit:
BEGIN AT THE SOUTHWEST CORNER OF THE NE 1/4 OF SECTION 9, TOWNSHIP 1 NORTH, RANGE 8 WEST, THENCE NORTH 00 DEGREES 23 MINUTES 56 SECONDS EAST 198.70 FEET, TO A CONCRETE MONUMENT LOCATED ON THE SOUTH SIDE RIGHT OF WAY LINE OF COUNTY GRADED ROAD, THENCE NORTH 00 DEGREES 23 MINUTES 56 SECONDS EAST 52.92 FEET, TO A CONCRETE MONUMENT LOCATED ON THE NORTH SIDE RIGHT OF WAY LINE OF COUNTY GRADED ROAD, THENCE NORTH 00 DEGREES 37 MINUTES 09 SECONDS EAST 178.73 FEET, TO A CONCRETE MONUMENT FOR POINT OF BEGINNING, THENCE NORTH 00 DEGREES 23 MINUTES 56 SECONDS EAST 178.70 FEET, TO A CONCRETE MONUMENT, THENCE SOUTH 88 DEGREES 37 MINUTES 09 SECONDS EAST 270.00 FEET, TO A CONCRETE MONUMENT, THENCE SOUTH 00 DEGREES 23 MINUTES 56 SECONDS WEST 178.70 FEET, TO A CONCRETE MONUMENT, THENCE NORTH 88 DEGREES 37 MINUTES 09 SECONDS WEST 270.00 FEET, TO THE POINT OF BEGINNING. ALSO, KNOWN AS PARCEL 2. LYING AND BEING IN THE NE 1/4 OF SECTION 9, TOWNSHIP 1 NORTH, RANGE 8 WEST. SAID LAND SITUATE AND LYING IN CALHOUN COUNTY, FLORIDA.
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the lis pendens, must file a claim within 60 days after the sale.
Dated this 30th day of September, 2009.
RUTH W. ATTAWAY
Clerk of the Circuit Court
Legal Notice
IN THE COUNTY COURT OF THE 14TH JUDICIAL CIRCUIT, IN AND FOR CALHOUN COUNTY,
FLORIDA
CASE NO.: 2009-20 CC
ALDA LAND HOLDING, LLC
Plaintiff,
v.
ALI KHAN HASHMAT,
Defendant.
NOTICE FOR (ACTION) PUBLICATION
TO: ALI KHAN HASHMAT
YOU ARE NOTIFIED of the institution of this action by plaintiff against you seeking to foreclose a construction lien on the following property in Calhoun County, Florida.
LOT 13 AND 14, BLOCK 2, LAKE CENTER PARK SUBDIVISION, LYING, AND BEING IN SECTION 28, TOWNSHIP 2 NORTH, RANGE 11 WEST, CALHOUN COUNTY, FLORIDA
has been filed against you and you are required to serve a copy of your written defenses, if any to it on Patricia M. Arias, Attorney for Plaintiff, whose address is 2701 S. Bayshore Drive, Suite 303, Miami, Florida 33133 and file the original with the Clerk of the above styled court on or before November 2, 2009, otherwise a default will be entered against you for the relief prayed for in the complaint or petition.
This notice shall be published once a week for two consecutive weeks in THE COUNTY RECORD.
Witness my hand and the seal of said Court at Calhoun County, Florida on October 6, 2009.
RUTH ATTAWAY,
Clerk of Court
Legal Notice
NOTICE OF DISPOSAL
M & W SELF STORAGE RENTALS will dispose of the contents of the following unit on Thursday, October 22, 2009, at 5:00 p.m. if not paid in full and emptied out. The unit is believed to contain household and/or personal property.
SHANNON KENT
TUPELO AVENUE
PROJECT # 14.092
NOTICE TO RECEIVE SEALED BIDS
The Calhoun County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing:
TUPELO AVENUE
Plans and specifications can be obtained at Preble-Rish, Inc., 324 Marina Drive, Port St. Joe, Florida 32456, (850) 227-7200. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
This project will consist of installing four 72” pipes with concrete end walls, and repairing the asphalt roadway.
All bidders shall be FDOT Qualified per Section 2-1 of the FDOT Standard Specifications for Road and Bridge Construction, latest edition.
Completion date for these projects will be 150 days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day.
Please indicate on the envelope that this is a sealed bid, the bid number and what the bid is for.
Bids will be received until 2:00 p.m. (C.T.), on Tuesday, October 20, 2009, at the Calhoun County Clerk’s Office, Calhoun County Courthouse, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424, and will be opened and read aloud on Tuesday, October 20, 2009 at 5:00 p.m. (C.T.).
Cost for Plans and Specifications will be $50.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC.
The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Calhoun County.
If you have any questions, please call Matt Carpenter at (850) 643-2771 or email carpenterm@preble-rish.com
Legal Notice
IN THE CIRCUIT COURT OF THE 14TH JUDICIAL CIRCUIT, IN AND FOR CALHOUN COUNTY,
FLORIDA GENERAL JURISDICTION DIVISION
CASE NO:2008-CA-000179
CITIMORTGAGE, INC.
PLAINTIFFS,
-vs-
KIWANIS G. NICHOLS JR.; APRIL GW NICHOLS; ANY AND ALL UNKNOWN PARTIES CLAIMING BY, THROUGH, UNDER, AND AGAINST THE HEREIN NAMED INDIVIDUAL DEFENDANT(S) WHO ARE NOT KNOWN TO BE DEAD OR ALIVE, WHETHER SAID UNKNOWN PARTIES MAY CLAIM AN INTEREST AS SPOUSES, HEIRS, DEVISEES, GRANTEES OR OTHER CLAIMANTS; JOHN DOE AND JANE JOE AS UNKNOWN TENANTS IN POSSESSION,
DEFENDANT(S)
NOTICE OF FORECLOSURE SALE
YOU ARE HEREBY NOTIFIED that pursuant to a Summary Final Judgment of Foreclosure dated September 30, 2009 entered in Civil Case No. 2008-CA-000179 of the Circuit Court of the 14TH Judicial Circuit in and for CALHOUN County, Blountstown, Florida, I will sell to the highest and best bidder for cash at ON THE FRONT STEPS OF THE COURTHOUSE at the CALHOUN County Courthouse located at 20859 SE Central Avenue East in Blountstown, Florida, at 11:00 a.m. CST, on the 29th day of October, 2009 the following described property as set forth in said Summary Final Judgment to-wit:
BEGIN AT THE SOUTHWEST CORNER OF THE NE 1/4 OF SECTION 9, TOWNSHIP 1 NORTH, RANGE 8 WEST, THENCE NORTH 00 DEGREES 23 MINUTES 56 SECONDS EAST 198.70 FEET, TO A CONCRETE MONUMENT LOCATED ON THE SOUTH SIDE RIGHT OF WAY LINE OF COUNTY GRADED ROAD, THENCE NORTH 00 DEGREES 23 MINUTES 56 SECONDS EAST 52.92 FEET, TO A CONCRETE MONUMENT LOCATED ON THE NORTH SIDE RIGHT OF WAY LINE OF COUNTY GRADED ROAD, THENCE NORTH 00 DEGREES 37 MINUTES 09 SECONDS EAST 178.73 FEET, TO A CONCRETE MONUMENT FOR POINT OF BEGINNING, THENCE NORTH 00 DEGREES 23 MINUTES 56 SECONDS EAST 178.70 FEET, TO A CONCRETE MONUMENT, THENCE SOUTH 88 DEGREES 37 MINUTES 09 SECONDS EAST 270.00 FEET, TO A CONCRETE MONUMENT, THENCE SOUTH 00 DEGREES 23 MINUTES 56 SECONDS WEST 178.70 FEET, TO A CONCRETE MONUMENT, THENCE NORTH 88 DEGREES 37 MINUTES 09 SECONDS WEST 270.00 FEET, TO THE POINT OF BEGINNING. ALSO, KNOWN AS PARCEL 2. LYING AND BEING IN THE NE 1/4 OF SECTION 9, TOWNSHIP 1 NORTH, RANGE 8 WEST. SAID LAND SITUATE AND LYING IN CALHOUN COUNTY, FLORIDA.
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the lis pendens, must file a claim within 60 days after the sale.
Dated this 30th day of September, 2009.
RUTH W. ATTAWAY
Clerk of the Circuit Court
Legal Notice
IN THE COUNTY COURT OF THE 14TH JUDICIAL CIRCUIT, IN AND FOR CALHOUN COUNTY,
FLORIDA
CASE NO.: 2009-20 CC
ALDA LAND HOLDING, LLC
Plaintiff,
v.
ALI KHAN HASHMAT,
Defendant.
NOTICE FOR (ACTION) PUBLICATION
TO: ALI KHAN HASHMAT
YOU ARE NOTIFIED of the institution of this action by plaintiff against you seeking to foreclose a construction lien on the following property in Calhoun County, Florida.
LOT 13 AND 14, BLOCK 2, LAKE CENTER PARK SUBDIVISION, LYING, AND BEING IN SECTION 28, TOWNSHIP 2 NORTH, RANGE 11 WEST, CALHOUN COUNTY, FLORIDA
has been filed against you and you are required to serve a copy of your written defenses, if any to it on Patricia M. Arias, Attorney for Plaintiff, whose address is 2701 S. Bayshore Drive, Suite 303, Miami, Florida 33133 and file the original with the Clerk of the above styled court on or before November 2, 2009, otherwise a default will be entered against you for the relief prayed for in the complaint or petition.
This notice shall be published once a week for two consecutive weeks in THE COUNTY RECORD.
Witness my hand and the seal of said Court at Calhoun County, Florida on October 6, 2009.
RUTH ATTAWAY,
Clerk of Court
Legal Notice
NOTICE OF DISPOSAL
M & W SELF STORAGE RENTALS will dispose of the contents of the following unit on Thursday, October 22, 2009, at 5:00 p.m. if not paid in full and emptied out. The unit is believed to contain household and/or personal property.
SHANNON KENT
Trackbacks
Trackback specific URI for this entry
No Trackbacks