Legal Notice
Legals for 08-01-13
CITY OF BLOUNTSTOWN NOTICE TO RECEIVE SEALED BIDS
The City of Blountstown will receive sealed bids from any qualified person, company or corporation interested in constructing:
2013 STREET PAVING
This project consists paving approximately 2.2 miles of various City streets and includes the construction of a truck parking lane along a portion of Canal Lane.
A MANDATORY PREBID MEETING WILL BE HELD ON WEDNESDAY AUGUST 14, 2013 AT 9:00 AM CST IN THE CITY COUNCIL MEETING ROOM AT 17276 NW ANGLE STREET
BLOUNTSTOWN, FL. 32424
Plans and specifications can be obtained from the City of Blountstown, 20591 Central Avenue Wes t, Blountstown, Florida 32424, (850) 674-5488. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
Bids will be received until 4:00 p.m.CST, on Tuesday, August 27, 2013 at Blountstown City Hall, 20591 Central Avenue West, Blountstown, Florida 32424, and will be opened and read publicly as soon as possible after 6:00 p.m. CST at 17276 NW Angle St. All Bids shall be submitted in a sealed envelope clearly marked “Sealed Bid – 2013 STREET PAVING.
Completion date for this project will be 60 calendar days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $150.00 per day.
The City of Blountstown reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of the City.
If you have any questions, please call Emory Pierce, City Manager at (850) 674 5488 or email at epierce@Blountstown.org
Legal Notice
CALHOUN COUNTY BOARD OF COUNTY COMMISSIONERS
NOTICE TO BIDDERS
Sealed proposals, in triplicate, will be received by the Calhoun County Board of County Commissioners until 12:00 p.m., August 14, 2013, local time, at Calhoun County Board of County Commissioner , 20859 Central Avenue East, Room 130, Blountstown, Florida 32424. Bids will be publicly opened and read aloud during the scheduled Calhoun County Board of County Commissioner Meeting that same day.
Bidders are invited to submit proposals for:
CONSTRUCT NORTH APRON
EXTENSION PHASE 2
AT THE CALHOUN COUNTY AIRPORT
It is the intent of this Bid to secure a contractor who will permit, procure and construct the North Apron Extension with all accessories as specified in the Technical Specifications section and the attached plans.
Bidders are invited to submit Proposals for this work on the Proposal Forms provided. Other proposal forms will not be accepted.
The complete examination and understanding of the Contract Documents consisting of the Plans and Specifications, and all addenda or other revisions, and Site of the proposed work is necessary to properly submit a Proposal. Contract Documents consisting of the Plans and Specifications, and all addenda or other revisions are available for examination or may be obtained from the offices of the URS Corporation, 7650 West Courtney Campbell Causeway, Tampa, Florida 33607, Phone (813) 286-1711, Fax (813) 638-2400. Please contact Diane Kline. There is a $100.00 charge for the plans and specifications. This cost is non-refundable.
This project is funded by both Federal Aviation Administration (FAA) AIP funds and by Florida Department of Transportation (FDOT) funds.
A Bid Bond in the form as bound in the Contract Documents or Certified Check in the amount of not less than five percent (5%) of the total amount bid must accompany each Bid.
Successful Bidder shall be required to execute and to provide a Payment Bond and Performance Bond each in an Amount of not less than one hundred percent (100%) of the total value of the Contract awarded to him with a satisfactory surety or sureties for the full and faithful performance of the work.
The Calhoun County Board of County Commissioners, in accordance with Title VI of the Civil Rights Act of 1964 (42 U.S.C. 2000d) and 49 CFR, Part 26 Participation by Disadvantaged Business Enterprises in Department of Transportation Programs, hereby notifies all bidders that it will affirmatively ensure that disadvantaged business enterprises are afforded full oppor?tunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, sex or national origin in consideration for an award.
No bid may be withdrawn after closing time for the receipt of Proposals for a period of one hundred twenty (120) days.
The Calhoun County Board of County Commissioners reserves the right to waive any informalities or irregularities in or reject any or all bids and to award or refrain from awarding the Contract for the Work.
Dated: 7/22/13
By:Calhoun County Board of County Commissioners
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT, IN AND FOR
CALHOUN COUNTY, FLORIDA
CASE NO: 2013-147-CA
HANCOCK BANK,
a Mississippi banking corporation,
Plaintiff,
-vs-
HENRY C. CALHOUN, and
LELA A. DOVER,
Defendants.
NOTICE OF ACTION
TO: HENRY C. CALHOUN:
YOU ARE NOTIFIED that a civil action has been filed against you in the Circuit Court, County of Calhoun, State of Florida, to foreclose certain real property described as follows:
THE SW 1/4 OF THE NE 14 OF SECTION 27, TOWNSHIP 2 SOUTH, RANGE 10 WEST, CALHOUN COUNTY, FLORIDA.
You are required to file a written response with the Court and serve a copy of your written defenses, if any, to it on Keith L. Bell, Jr., Plaintiff’s attorney, whose address is 106 East College Avenue, Suite 600, Tallahassee, Florida 32301, at least thirty (30) days from the date of first publication, and file the original with the clerk of this court either before service on Plaintiff’s attorney or immediately thereafter; otherwise, a default will be entered against you for the relief demanded in the complaint.
Dated this 15th day of July, 2013.
CARLA A. HAND
CLERK OF COURT
Legal Notice
IN THE CIRCUIT COURT FOR CALHOUN COUNTY, FLORIDA
PROBATE DIVISION
File No. 2013-36 PR
In Re: Estate of:
THOMAS S. SMITH,
a/k/a TOMMY S. SMITH,
Deceased.
NOTICE TO CREDITORS
The administration of the Estate of Thomas S. Smith, a/k/a Tommy S. Smith, deceased, whose date of death was June 18, 2013, and whose Social Security Number is xxx-xx-6563, is pending in the Circuit Court for Calhoun County, Florida, Probate Division, File Number 2013-36 PR, the address of which is c/o Carla Hand, Clerk of Court, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424. The name and address of the personal representative and the personal representative’s attorney are set forth below.
All creditors of the decedent and other persons having claims or demands against decedent’s estate on whom a copy of this notice has been served must file their claims with this Court WITHIN THE LATER OF THREE (3) MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE OR THIRTY (30) DAYS AFTER THE TIME OF SERVICE OF A COPY OF THIS NOTICE ON THEM.
All other creditors of the decedent and other persons having claims or demands against decedent’s estate must file their claims with this Court WITHIN THREE (3) MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE.
ALL CLAIMS NOT FILED WITHIN THE TIME PERIODS SET FORTH IN SECTION 733.702 OF THE FLORIDA PROBATE CODE WILL BE FOREVER BARRED.
NOTWITHSTANDING THE TIME PERIOD SET FORTH ABOVE, ANY CLAIM FILED TWO (2) YEARS OR MORE AFTER THE DECEDENT’S DATE OF DEATH IS BARRED.
The date of first publication of this notice is July 24, 2013.
THOMAS S. SMITH, JR.
3422 GREY ROAD WA
MARIANNA, FL 32446
Attorney for Personal Representative:
s/Frank E. Bondurant
Florida Bar No: 0520330
BONDURANT AND FUQUA, P.A.
4450 Lafayette Street
Post Office Box 1508
Marianna, Florida 32447
(850) 526-2263
Email: fbondurant@bffloridalaw.com
Legal Notice
IN THE CIRCUIT COURT FO
CALHOUN COUNTY, FLORIDA
PROBATE DIVISION
IN RE: ESTATE OF
NESBIE MING DUPUY,
Deceased.
File No. 2013-39-PR
NOTICE TO CREDITORS
The administration of the estate of Nesbie Ming Dupuy, deceased, whose date of death was May 29, 2013, is pending in the Circuit Court for Calhoun County, Florida, Probate Division, the address of which is 20859 Central Ave., E Room 130, Blountstown, FL 32424. The names and addresses of the personal representative and the personal representative’s attorney are set forth below.
All creditors of the decedent and other persons having claims or demands against decedent’s estate on whom a copy of this notice is required to be served must file their claims with this court ON OR BEFORE THE LATER OF 3 MONTHS AFTER THE TIME OF THE FIRST PUBLICATION OF THIS NOTICE OR 30 DAYS AFTER THE DATE OF SERVICE OF A COPY OF THIS NOTICE ON THEM.
All other creditors of the decedent and other persons having claims or demands against decedent’s estate must file their claims with this court WITHIN 3 MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE.
ALL CLAIMS NOT FILED WITHIN THE TIME PERIODS SET FORTH IN SECTION 733.702 OF THE FLORIDA PROBATE CODE WILL BE FOREVER BARRED.
NOTWITHSTANDING THE TIME PERIOD SET FORTH ABOVE, ANY CLAIM FILED TWO (2) YEARS OR MORE AFTER THE DECEDENT’S DATE OF DEATH IS BARRED.
The date of first publication of this notice is July 31, 2013.
Personal Representative:
Victor J. Dupuy, Sr.
P.O. Box 240
Blountstown, FL 32424
Attorney for Personal Representative:
Angela Warren
Florida Bar No. 0728632
Pope & Barloga P.A.
736 Jenks Ave.
P.O. Box 1609
Panama City, FL 32402
Telephone: (850)784-9174
E-Mail Addresses:
awarren@popebarloga.com
estanton@popebarloga.com
Legal Notice
IN THE CIRCUIT COURT, FOURTEENTH JUDICIAL CIRCUIT OF THE STATE OF FLORIDA, IN AND FOR CALHOUN COUNTY
CASE NUMBER: 13-71-CA
PETER C. RAY, TRUSTEE UNDER PARTNERSHIP AGREEMENT
DATED MAY 30, 1998, JOINED BY ALL THE PARTNERS
UNDER THE AFOREMENTIONED AGREEMENT: PETER C. RAY,
AS TRUSTEE OF THE PETER C. RAY TRUST UNDER AGREEMENT
DATED JUNE 17, 1971 AND SPIVEY’S CONSTRUCTION COMPANY,
INC., a Florida corporation,
Plaintiffs,
vs.
CARL ROMAIN, IF MARRIED HIS UNKNOWN SPOUSE,
AND IF DECEASED, THE UNKNOWN HEIRS, DEVISEES,
CREDITORS, GRANTEES AND ALL PERSONS
CLAIMING BY, THROUGH, UNDER OR AGAINST HIM,
Defendants.
NOTICE OF SALE
NOTICE is hereby given that pursuant to a Summary Final Judgment in Foreclosure dated the 23rd day of July, 2013 in the above-styled cause, I will sell to the highest bidder for cash at the front steps of the Calhoun County Courthouse in Blountstown, Florida at 11:00 a.m. (CT), on August 29, 2013, the following described property set forth in the Summary Final Judgment:
Lot 9 of Serenity Subdivision, according to the Plat thereof as recorded in Plat Book 2, Page(s) 86, of the Public Records of Calhoun County, Florida.
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the Lis Pendens must file a claim within sixty (60) days after the sale.
WITNESS my hand and seal of the Court on the 23rd day of July, 2013.
Clerk of the Circuit Court
By: Lori Flowers
Deputy Clerk
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT IN AND FOR
CALHOUN COUNTY, FLORIDA
CIVIL ACTION
CASE NO. 07-2012-CA-000015
BANK OF AMERICA, N.A., SUCCESSOR BY MERGER TO BAC HOME LOANS SERVICING, LP FKA COUNTRYWIDE HOME LOANS SERVICING LP,
Plaintiff,
-vs-
TERESA A. VAUGHN, et al,
Defendant(s).
NOTICE OF FORECLOSURE SALE
NOTICE IS HEREBY GIVEN pursuant to a Final Judgment of Mortgage Foreclosure dated July 23, 2012 and entered in Case No. 07-2012-ca-000015 of the Circuit Court of the FOURTEENTH Judicial Circuit in and for CALHOUN County, Florida wherein BANK OF AMERICA, N.A., SUCCESSOR BY MERGER TO BAC HOME LOANS SERVICING, LP FKA COUNTRYWIDE HOME LOANS SERVICING LP is the Plaintiff and TERESA A. VAUGHN; DAVID WILLIAMS A/K/A DAVID W. WILLIAMS; ANY AND ALL UNKNOWN PARTIES CLAIMING BY, THROUGH, UNDER, AND AGAINST THE HEREIN NAMED INDIVIDUAL DEFENDANT(S) WHO ARE NOT KNOWN TO BE DEAD OR ALIVE, WHETHER SAID UNKNOWN PARTIES MAY CLAIM AN INTEREST AS SPOUSES, HEIRS, DEVISEES, GRANTEES, OR OTHER CLAIMANTS; WEST FLORIDA ELECTRIC COOPERATIVE ASSOCIATION, INC. D/B/A WEST FLORIDA ELECTRIC; are the Defendants, The Clerk of the Court will sell to the highest and best bidder for cash at the LOBBY OF THE CALHOUN COUNTY COURTHOUSE, 20859 E. Central Ave., Blountstown, FL. 32424 at 11:00 a.m. CT, on the 5th day of September, 2013, the following described property as set forth in said Final Judgment:
BEGIN AT THE EDGE OF BROAD STREET IN THE TOWN OF ALTHA, FLORIDA IN THE SOUTHEAST CORNER OF THE SOUTHEAST 1/4 OF NORTHEAST 1/4 OF SECTION 15, TOWNSHIP 2 NORTH, RANGE 9 WEST; THENCE RUN WEST UP SAID STREET 48 YARDS; THENCE RUN NORTH 70 YARDS; THENCE RUN EAST 48 YARDS; THENCE RUN SOUTH 70 YARDS TO THE POINT OF BEGINNING.
A/K/A 16214 NE BROAD ST., ALTHA, FL 32421
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the Lis pendens must file a claim within sixty (60) days after the sale.
WITNESS MY HAND and the sale of this Court on July 24, 2013.
Carla A. Hand
Clerk of the Circuit Court
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUI
IN AND FOR
CALHOUN COUNTY, FLORIDA
CIVIL ACTION
CASE NO. 07-2011-CA-000191
BAC HOME LOANS SERVICING, LP FKA COUNTRYWIDE HOME LOANS SERVICING LP,
Plaintiff,
-vs-
ALICE LAVERNE MELTON A/K/A ALICE L. MELTON A/K/A LAVERNE MELTON et al,
Defendant(s).
NOTICE OF FORECLOSURE SALE
NOTICE IS HEREBY GIVEN pursuant to a Final Judgment of Mortgage Foreclosure dated July 23, 2012 and entered in Case No. 07-2011-CA-000191 of the Circuit Court of the FOURTEENTH Judicial Circuit in and for CALHOUN County, Florida wherein BAC HOME LOANS SERVICING, LP FKA COUNTRYWIDE HOME LOANS SERVICING LP is the Plaintiff and ALICE LAVERNE MELTON A/K/A ALICE L. MELTON A/K/A LAVERNE MELTON; JAMES WILLIAM MELTON; TENANT #1 N/K/A JASON MELTON, and TENANT #2 N/K/A JENNIFER BRANNING are the Defendants, The Clerk of the Court will sell to the highest and best bidder for cash at the LOBBY OF THE CALHOUN COUNTY COURTHOUSE, 20859 E. Central Ave., Blountstown, FL. 32424 at 11:00 a.m. CT, on the 5th day of September, 2013, the following described property as set forth in said Final Judgment:
COMMENCING AT A 5/8 INCH IRON ROD AND CAP MARKING THE SOUTHWEST CORNER OF SECTION 14, TOWNSHIP 2 NORTH, RANGE 9 WEST, CALHOUN COUNTY, FLORIDA, AND RUN THENCE NORTH, A DISTANCE OF 44.34 FEET TO THE NORTHERLY MAINTAINED RIGHT OF WAY BOUNDARY OF HANNA TOWER ROAD; THENCE NORTH 87 DEGREES 41 MINUTES 47 SECONDS EAST ALONG SAID NORTHERLY, MAINTAINED RIGHT OF WAY BOUNDARY, A DISTANCE OF 820.98 FEET, TO THE POINT OF BEGINNING. FROM SAID POINT OF BEGINNING, THENCE NORTH 03 DEGREES 57 MINUTES 07 SECONDS WEST, A DISTANCE OF 378.16 FEET, THENCE NORTH 86 DEGREES 02 MINUTES 53 SECONDS EAST, A DISTANCE OF 230.38 FEET, THENCE SOUTH 03 DEGREES 57 MINUTES 07 SECONDS EAST, A DISTANCE OF 378.16 FEET, TO THE AFORESAID NORTHERLY MAINTAINED RIGHT OF WAY BOUNDARY; THENCE SOUTH 86 DEGREES 02 MINUTES 53 SECONDS WEST ALONG SAID NORTHERLY MAINTAINED RIGHT OF WAY BOUNDARY, A DISTANCE OF 230.38 FEET, TO THE POINT OF BEGINNING
A/K/A 17304 NE HANNA TOWER ROAD, ALTHA, FL 32421
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the Lis pendens must file a claim within sixty (60) days after the sale.
WITNESS MY HAND and the sale of this Court on July 24, 2013.
Carla A. Hand
Clerk of the Circuit Court
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL COURT IN AND FOR CALHOUN
COUNTY, FLORIDA
CIVIL DIVISION
CASE NO. 072012CA000011XXXXXX
BANK OF AMERICA, N.A., SUCCESSOR BY MERGER TO BAC HOME LOANS SERVICING, LP,
Plaintiff,
-vs-
KIEL M. GODWIN; et al,
Defendants.
NOTICE OF SALE
PURSUANT TO CHAPTER 45
NOTICE IS HEREBY GIVEN pursuant to an Order or Summary Final Judgment of foreclosure dated July 25, 2013, and entered in Case No. 072012CA000011XXXXXX of the Circuit Court in and for Calhoun County, Florida, where BANK OF AMERICA, NA., SUCCESSOR BY MERGER TO BAC HOME LOANS SERVICING, LP is Plaintiff and KIEL M. GODWIN; ASHLEY GODWIN; UNKNOWN TENANT NO. 1; UNKNOWN TENANT NO. 2; and ALL UNKNOWN PARTIES CLAIMING INTERESTS BY, THROUGH, UNDER OR AGAINST A NAMED DEFENDANT TO THIS ACTION, OR HAVING OR CLAIMING TO HAVE ANY RIGHT, TITLE OR INTEREST IN THE PROPERTY HEREIN DESCRIBED, are Defendants, I will sell to the highest and best bidder for cash on the Front Steps of the Calhoun County Courthouse at 425 E. Central Avenue, Blountstown, FL 324242 County, Florida, 11:00 a.m. CST on the 10th day of October, 2013, the following described property as set forth in said Order or Final Judgment to-wit:
EAST HALF OF LOT NUMBER FOUR AND WEST HALF OF LOT NUMBER THREE IN BLOCK “O”, ACCORDING TO THE PLAT OF HOBB’S ADDITION TO THE TOWN OF BLOUNTSTOWN, FLORIDA. BEING A PART OF SOUTHWEST 1/4 OF NORTHWEST 1/4 OF SECTION 28, TOWNSHIP 1 NORTH, RANGE 8 WEST, CALHOUN COUNTY, FLORIDA.
ANY PERSON CLAIMING AN INTEREST IN THE SURPLUS FROM THE SALE, IF ANY, OTHER THAN THE PROPERTY OWNER AS OF THE DATE OF THE LIS PENDENS MUST FILE A CLAIM WITHIN 60 DAYS AFTER THE SALE.
If you are a person with a disability who needs any accommodation in order to participate in this proceeding, you are entitled, at no cost to you, to the provision of certain assistance. Please contact the ADA Coordinator by mail at P.O. Box 1089, Panama City, FL 32402 at (850) 747-5338, at least seven (7) days before your scheduled court appearance, or immediately upon receiving this notification if the time before the scheduled appearance is les than seven (7) days. If you are hearing impaired, call 711.
DATED at Blountstown, Florida, on July 25, 2013.
CARLA A. HAND
As Clerk of Circuit Court
By: Lori Flowers
As Deputy Clerk
Legal Notice
NOTICE OF PUBLIC SALE
MALLORY TOWING & RECOVERY, INC. gives Notice of Foreclosure of Lien and intent to sell these vehicles on August 12, 2013, 2:00 p.m. at 18114 SR 20 W., BLOUNTSTOWN, FL 32424-4834, pursuant to subsection 713.78 of the Florida Statutes. MALLORY TOWING & RECOVERY, INC. reserves the right to accept or reject any and/or all bids.
2003 CHRYSLER
2C3HE66G63H511101
MALLORY TOWING & RECOVERY, INC.
Legal Notice
NOTICE OF PUBLIC SALE
MALLORY TOWING & RECOVERY, INC. gives Notice of Foreclosure of Lien and intent to sell these vehicles on August 12, 2013, 2:00 p.m. at 18114 SR 20 W., BLOUNTSTOWN, FL 32424-4834, pursuant to subsection 713.78 of the Florida Statutes. MALLORY TOWING & RECOVERY, INC. reserves the right to accept or reject any and/or all bids.
1991 TOYOTA
JT4RN81A3M0068779
MALLORY TOWING & RECOVERY, INC.
Legal Notice
NOTICE OF APPLICATION FOR
TAX DEED
NOTICE IS HEREBY GIVEN THAT Rose Burg is the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number and year of issuance, the description of the property, and the names in which it was assessed are as follows;
CERTIFICATE NO.541 YEAR OF 2011
DESCRIPTION OF PROPERTY
Parcel # R31-2N-10-0000-0003-1001
A part of Lot 10 of Fitzsimons unrecorded subdivision, located in the S1/2 of the N1/2 of Section 31, Township 2 North, Range 10 West, Calhoun County, Florida, more particularly described as follows: Commence at the Southwest Corner of the NW 1/4 of Section 31, Township 2 North, Range 10 West, thence run South 85 degrees 51 minutes 38 seconds East 2163.97 feet to the POINT OF BEGINNING; thence continue South 85 degrees 51 minutes 38 seconds East 200 feet; thence North 05 degrees 03 minutes 50 seconds East 100 feet; thence run North 85 degrees 51 minutes 38 seconds West 200 feet; thence run South 05 degrees 03 minutes 50 seconds West 100 feet, back to the POINT OF BEGINNING. Containing .46 acres, more or less.
NAME IN WHICH ASSESSED
George Noah
718 S. Conkling
Baltimore, MD 21224
Said property being in the County of CALHOUN, STATE OF FLORIDA. Unless such certificate shall be redeemed according to law, the property described in such certificate shall be SOLD to the highest bidder at the Courthouse door on September 5, 2013 at 10:00 A.M. CST.
By; Robie Bennett
Deputy Clerk CARLA A. HAND
Clerk of Circuit Court of
Calhoun County, Florida
The City of Blountstown will receive sealed bids from any qualified person, company or corporation interested in constructing:
2013 STREET PAVING
This project consists paving approximately 2.2 miles of various City streets and includes the construction of a truck parking lane along a portion of Canal Lane.
A MANDATORY PREBID MEETING WILL BE HELD ON WEDNESDAY AUGUST 14, 2013 AT 9:00 AM CST IN THE CITY COUNCIL MEETING ROOM AT 17276 NW ANGLE STREET
BLOUNTSTOWN, FL. 32424
Plans and specifications can be obtained from the City of Blountstown, 20591 Central Avenue Wes t, Blountstown, Florida 32424, (850) 674-5488. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
Bids will be received until 4:00 p.m.CST, on Tuesday, August 27, 2013 at Blountstown City Hall, 20591 Central Avenue West, Blountstown, Florida 32424, and will be opened and read publicly as soon as possible after 6:00 p.m. CST at 17276 NW Angle St. All Bids shall be submitted in a sealed envelope clearly marked “Sealed Bid – 2013 STREET PAVING.
Completion date for this project will be 60 calendar days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $150.00 per day.
The City of Blountstown reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of the City.
If you have any questions, please call Emory Pierce, City Manager at (850) 674 5488 or email at epierce@Blountstown.org
Legal Notice
CALHOUN COUNTY BOARD OF COUNTY COMMISSIONERS
NOTICE TO BIDDERS
Sealed proposals, in triplicate, will be received by the Calhoun County Board of County Commissioners until 12:00 p.m., August 14, 2013, local time, at Calhoun County Board of County Commissioner , 20859 Central Avenue East, Room 130, Blountstown, Florida 32424. Bids will be publicly opened and read aloud during the scheduled Calhoun County Board of County Commissioner Meeting that same day.
Bidders are invited to submit proposals for:
CONSTRUCT NORTH APRON
EXTENSION PHASE 2
AT THE CALHOUN COUNTY AIRPORT
It is the intent of this Bid to secure a contractor who will permit, procure and construct the North Apron Extension with all accessories as specified in the Technical Specifications section and the attached plans.
Bidders are invited to submit Proposals for this work on the Proposal Forms provided. Other proposal forms will not be accepted.
The complete examination and understanding of the Contract Documents consisting of the Plans and Specifications, and all addenda or other revisions, and Site of the proposed work is necessary to properly submit a Proposal. Contract Documents consisting of the Plans and Specifications, and all addenda or other revisions are available for examination or may be obtained from the offices of the URS Corporation, 7650 West Courtney Campbell Causeway, Tampa, Florida 33607, Phone (813) 286-1711, Fax (813) 638-2400. Please contact Diane Kline. There is a $100.00 charge for the plans and specifications. This cost is non-refundable.
This project is funded by both Federal Aviation Administration (FAA) AIP funds and by Florida Department of Transportation (FDOT) funds.
A Bid Bond in the form as bound in the Contract Documents or Certified Check in the amount of not less than five percent (5%) of the total amount bid must accompany each Bid.
Successful Bidder shall be required to execute and to provide a Payment Bond and Performance Bond each in an Amount of not less than one hundred percent (100%) of the total value of the Contract awarded to him with a satisfactory surety or sureties for the full and faithful performance of the work.
The Calhoun County Board of County Commissioners, in accordance with Title VI of the Civil Rights Act of 1964 (42 U.S.C. 2000d) and 49 CFR, Part 26 Participation by Disadvantaged Business Enterprises in Department of Transportation Programs, hereby notifies all bidders that it will affirmatively ensure that disadvantaged business enterprises are afforded full oppor?tunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, sex or national origin in consideration for an award.
No bid may be withdrawn after closing time for the receipt of Proposals for a period of one hundred twenty (120) days.
The Calhoun County Board of County Commissioners reserves the right to waive any informalities or irregularities in or reject any or all bids and to award or refrain from awarding the Contract for the Work.
Dated: 7/22/13
By:Calhoun County Board of County Commissioners
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT, IN AND FOR
CALHOUN COUNTY, FLORIDA
CASE NO: 2013-147-CA
HANCOCK BANK,
a Mississippi banking corporation,
Plaintiff,
-vs-
HENRY C. CALHOUN, and
LELA A. DOVER,
Defendants.
NOTICE OF ACTION
TO: HENRY C. CALHOUN:
YOU ARE NOTIFIED that a civil action has been filed against you in the Circuit Court, County of Calhoun, State of Florida, to foreclose certain real property described as follows:
THE SW 1/4 OF THE NE 14 OF SECTION 27, TOWNSHIP 2 SOUTH, RANGE 10 WEST, CALHOUN COUNTY, FLORIDA.
You are required to file a written response with the Court and serve a copy of your written defenses, if any, to it on Keith L. Bell, Jr., Plaintiff’s attorney, whose address is 106 East College Avenue, Suite 600, Tallahassee, Florida 32301, at least thirty (30) days from the date of first publication, and file the original with the clerk of this court either before service on Plaintiff’s attorney or immediately thereafter; otherwise, a default will be entered against you for the relief demanded in the complaint.
Dated this 15th day of July, 2013.
CARLA A. HAND
CLERK OF COURT
Legal Notice
IN THE CIRCUIT COURT FOR CALHOUN COUNTY, FLORIDA
PROBATE DIVISION
File No. 2013-36 PR
In Re: Estate of:
THOMAS S. SMITH,
a/k/a TOMMY S. SMITH,
Deceased.
NOTICE TO CREDITORS
The administration of the Estate of Thomas S. Smith, a/k/a Tommy S. Smith, deceased, whose date of death was June 18, 2013, and whose Social Security Number is xxx-xx-6563, is pending in the Circuit Court for Calhoun County, Florida, Probate Division, File Number 2013-36 PR, the address of which is c/o Carla Hand, Clerk of Court, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424. The name and address of the personal representative and the personal representative’s attorney are set forth below.
All creditors of the decedent and other persons having claims or demands against decedent’s estate on whom a copy of this notice has been served must file their claims with this Court WITHIN THE LATER OF THREE (3) MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE OR THIRTY (30) DAYS AFTER THE TIME OF SERVICE OF A COPY OF THIS NOTICE ON THEM.
All other creditors of the decedent and other persons having claims or demands against decedent’s estate must file their claims with this Court WITHIN THREE (3) MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE.
ALL CLAIMS NOT FILED WITHIN THE TIME PERIODS SET FORTH IN SECTION 733.702 OF THE FLORIDA PROBATE CODE WILL BE FOREVER BARRED.
NOTWITHSTANDING THE TIME PERIOD SET FORTH ABOVE, ANY CLAIM FILED TWO (2) YEARS OR MORE AFTER THE DECEDENT’S DATE OF DEATH IS BARRED.
The date of first publication of this notice is July 24, 2013.
THOMAS S. SMITH, JR.
3422 GREY ROAD WA
MARIANNA, FL 32446
Attorney for Personal Representative:
s/Frank E. Bondurant
Florida Bar No: 0520330
BONDURANT AND FUQUA, P.A.
4450 Lafayette Street
Post Office Box 1508
Marianna, Florida 32447
(850) 526-2263
Email: fbondurant@bffloridalaw.com
Legal Notice
IN THE CIRCUIT COURT FO
CALHOUN COUNTY, FLORIDA
PROBATE DIVISION
IN RE: ESTATE OF
NESBIE MING DUPUY,
Deceased.
File No. 2013-39-PR
NOTICE TO CREDITORS
The administration of the estate of Nesbie Ming Dupuy, deceased, whose date of death was May 29, 2013, is pending in the Circuit Court for Calhoun County, Florida, Probate Division, the address of which is 20859 Central Ave., E Room 130, Blountstown, FL 32424. The names and addresses of the personal representative and the personal representative’s attorney are set forth below.
All creditors of the decedent and other persons having claims or demands against decedent’s estate on whom a copy of this notice is required to be served must file their claims with this court ON OR BEFORE THE LATER OF 3 MONTHS AFTER THE TIME OF THE FIRST PUBLICATION OF THIS NOTICE OR 30 DAYS AFTER THE DATE OF SERVICE OF A COPY OF THIS NOTICE ON THEM.
All other creditors of the decedent and other persons having claims or demands against decedent’s estate must file their claims with this court WITHIN 3 MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE.
ALL CLAIMS NOT FILED WITHIN THE TIME PERIODS SET FORTH IN SECTION 733.702 OF THE FLORIDA PROBATE CODE WILL BE FOREVER BARRED.
NOTWITHSTANDING THE TIME PERIOD SET FORTH ABOVE, ANY CLAIM FILED TWO (2) YEARS OR MORE AFTER THE DECEDENT’S DATE OF DEATH IS BARRED.
The date of first publication of this notice is July 31, 2013.
Personal Representative:
Victor J. Dupuy, Sr.
P.O. Box 240
Blountstown, FL 32424
Attorney for Personal Representative:
Angela Warren
Florida Bar No. 0728632
Pope & Barloga P.A.
736 Jenks Ave.
P.O. Box 1609
Panama City, FL 32402
Telephone: (850)784-9174
E-Mail Addresses:
awarren@popebarloga.com
estanton@popebarloga.com
Legal Notice
IN THE CIRCUIT COURT, FOURTEENTH JUDICIAL CIRCUIT OF THE STATE OF FLORIDA, IN AND FOR CALHOUN COUNTY
CASE NUMBER: 13-71-CA
PETER C. RAY, TRUSTEE UNDER PARTNERSHIP AGREEMENT
DATED MAY 30, 1998, JOINED BY ALL THE PARTNERS
UNDER THE AFOREMENTIONED AGREEMENT: PETER C. RAY,
AS TRUSTEE OF THE PETER C. RAY TRUST UNDER AGREEMENT
DATED JUNE 17, 1971 AND SPIVEY’S CONSTRUCTION COMPANY,
INC., a Florida corporation,
Plaintiffs,
vs.
CARL ROMAIN, IF MARRIED HIS UNKNOWN SPOUSE,
AND IF DECEASED, THE UNKNOWN HEIRS, DEVISEES,
CREDITORS, GRANTEES AND ALL PERSONS
CLAIMING BY, THROUGH, UNDER OR AGAINST HIM,
Defendants.
NOTICE OF SALE
NOTICE is hereby given that pursuant to a Summary Final Judgment in Foreclosure dated the 23rd day of July, 2013 in the above-styled cause, I will sell to the highest bidder for cash at the front steps of the Calhoun County Courthouse in Blountstown, Florida at 11:00 a.m. (CT), on August 29, 2013, the following described property set forth in the Summary Final Judgment:
Lot 9 of Serenity Subdivision, according to the Plat thereof as recorded in Plat Book 2, Page(s) 86, of the Public Records of Calhoun County, Florida.
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the Lis Pendens must file a claim within sixty (60) days after the sale.
WITNESS my hand and seal of the Court on the 23rd day of July, 2013.
Clerk of the Circuit Court
By: Lori Flowers
Deputy Clerk
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT IN AND FOR
CALHOUN COUNTY, FLORIDA
CIVIL ACTION
CASE NO. 07-2012-CA-000015
BANK OF AMERICA, N.A., SUCCESSOR BY MERGER TO BAC HOME LOANS SERVICING, LP FKA COUNTRYWIDE HOME LOANS SERVICING LP,
Plaintiff,
-vs-
TERESA A. VAUGHN, et al,
Defendant(s).
NOTICE OF FORECLOSURE SALE
NOTICE IS HEREBY GIVEN pursuant to a Final Judgment of Mortgage Foreclosure dated July 23, 2012 and entered in Case No. 07-2012-ca-000015 of the Circuit Court of the FOURTEENTH Judicial Circuit in and for CALHOUN County, Florida wherein BANK OF AMERICA, N.A., SUCCESSOR BY MERGER TO BAC HOME LOANS SERVICING, LP FKA COUNTRYWIDE HOME LOANS SERVICING LP is the Plaintiff and TERESA A. VAUGHN; DAVID WILLIAMS A/K/A DAVID W. WILLIAMS; ANY AND ALL UNKNOWN PARTIES CLAIMING BY, THROUGH, UNDER, AND AGAINST THE HEREIN NAMED INDIVIDUAL DEFENDANT(S) WHO ARE NOT KNOWN TO BE DEAD OR ALIVE, WHETHER SAID UNKNOWN PARTIES MAY CLAIM AN INTEREST AS SPOUSES, HEIRS, DEVISEES, GRANTEES, OR OTHER CLAIMANTS; WEST FLORIDA ELECTRIC COOPERATIVE ASSOCIATION, INC. D/B/A WEST FLORIDA ELECTRIC; are the Defendants, The Clerk of the Court will sell to the highest and best bidder for cash at the LOBBY OF THE CALHOUN COUNTY COURTHOUSE, 20859 E. Central Ave., Blountstown, FL. 32424 at 11:00 a.m. CT, on the 5th day of September, 2013, the following described property as set forth in said Final Judgment:
BEGIN AT THE EDGE OF BROAD STREET IN THE TOWN OF ALTHA, FLORIDA IN THE SOUTHEAST CORNER OF THE SOUTHEAST 1/4 OF NORTHEAST 1/4 OF SECTION 15, TOWNSHIP 2 NORTH, RANGE 9 WEST; THENCE RUN WEST UP SAID STREET 48 YARDS; THENCE RUN NORTH 70 YARDS; THENCE RUN EAST 48 YARDS; THENCE RUN SOUTH 70 YARDS TO THE POINT OF BEGINNING.
A/K/A 16214 NE BROAD ST., ALTHA, FL 32421
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the Lis pendens must file a claim within sixty (60) days after the sale.
WITNESS MY HAND and the sale of this Court on July 24, 2013.
Carla A. Hand
Clerk of the Circuit Court
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUI
IN AND FOR
CALHOUN COUNTY, FLORIDA
CIVIL ACTION
CASE NO. 07-2011-CA-000191
BAC HOME LOANS SERVICING, LP FKA COUNTRYWIDE HOME LOANS SERVICING LP,
Plaintiff,
-vs-
ALICE LAVERNE MELTON A/K/A ALICE L. MELTON A/K/A LAVERNE MELTON et al,
Defendant(s).
NOTICE OF FORECLOSURE SALE
NOTICE IS HEREBY GIVEN pursuant to a Final Judgment of Mortgage Foreclosure dated July 23, 2012 and entered in Case No. 07-2011-CA-000191 of the Circuit Court of the FOURTEENTH Judicial Circuit in and for CALHOUN County, Florida wherein BAC HOME LOANS SERVICING, LP FKA COUNTRYWIDE HOME LOANS SERVICING LP is the Plaintiff and ALICE LAVERNE MELTON A/K/A ALICE L. MELTON A/K/A LAVERNE MELTON; JAMES WILLIAM MELTON; TENANT #1 N/K/A JASON MELTON, and TENANT #2 N/K/A JENNIFER BRANNING are the Defendants, The Clerk of the Court will sell to the highest and best bidder for cash at the LOBBY OF THE CALHOUN COUNTY COURTHOUSE, 20859 E. Central Ave., Blountstown, FL. 32424 at 11:00 a.m. CT, on the 5th day of September, 2013, the following described property as set forth in said Final Judgment:
COMMENCING AT A 5/8 INCH IRON ROD AND CAP MARKING THE SOUTHWEST CORNER OF SECTION 14, TOWNSHIP 2 NORTH, RANGE 9 WEST, CALHOUN COUNTY, FLORIDA, AND RUN THENCE NORTH, A DISTANCE OF 44.34 FEET TO THE NORTHERLY MAINTAINED RIGHT OF WAY BOUNDARY OF HANNA TOWER ROAD; THENCE NORTH 87 DEGREES 41 MINUTES 47 SECONDS EAST ALONG SAID NORTHERLY, MAINTAINED RIGHT OF WAY BOUNDARY, A DISTANCE OF 820.98 FEET, TO THE POINT OF BEGINNING. FROM SAID POINT OF BEGINNING, THENCE NORTH 03 DEGREES 57 MINUTES 07 SECONDS WEST, A DISTANCE OF 378.16 FEET, THENCE NORTH 86 DEGREES 02 MINUTES 53 SECONDS EAST, A DISTANCE OF 230.38 FEET, THENCE SOUTH 03 DEGREES 57 MINUTES 07 SECONDS EAST, A DISTANCE OF 378.16 FEET, TO THE AFORESAID NORTHERLY MAINTAINED RIGHT OF WAY BOUNDARY; THENCE SOUTH 86 DEGREES 02 MINUTES 53 SECONDS WEST ALONG SAID NORTHERLY MAINTAINED RIGHT OF WAY BOUNDARY, A DISTANCE OF 230.38 FEET, TO THE POINT OF BEGINNING
A/K/A 17304 NE HANNA TOWER ROAD, ALTHA, FL 32421
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the Lis pendens must file a claim within sixty (60) days after the sale.
WITNESS MY HAND and the sale of this Court on July 24, 2013.
Carla A. Hand
Clerk of the Circuit Court
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL COURT IN AND FOR CALHOUN
COUNTY, FLORIDA
CIVIL DIVISION
CASE NO. 072012CA000011XXXXXX
BANK OF AMERICA, N.A., SUCCESSOR BY MERGER TO BAC HOME LOANS SERVICING, LP,
Plaintiff,
-vs-
KIEL M. GODWIN; et al,
Defendants.
NOTICE OF SALE
PURSUANT TO CHAPTER 45
NOTICE IS HEREBY GIVEN pursuant to an Order or Summary Final Judgment of foreclosure dated July 25, 2013, and entered in Case No. 072012CA000011XXXXXX of the Circuit Court in and for Calhoun County, Florida, where BANK OF AMERICA, NA., SUCCESSOR BY MERGER TO BAC HOME LOANS SERVICING, LP is Plaintiff and KIEL M. GODWIN; ASHLEY GODWIN; UNKNOWN TENANT NO. 1; UNKNOWN TENANT NO. 2; and ALL UNKNOWN PARTIES CLAIMING INTERESTS BY, THROUGH, UNDER OR AGAINST A NAMED DEFENDANT TO THIS ACTION, OR HAVING OR CLAIMING TO HAVE ANY RIGHT, TITLE OR INTEREST IN THE PROPERTY HEREIN DESCRIBED, are Defendants, I will sell to the highest and best bidder for cash on the Front Steps of the Calhoun County Courthouse at 425 E. Central Avenue, Blountstown, FL 324242 County, Florida, 11:00 a.m. CST on the 10th day of October, 2013, the following described property as set forth in said Order or Final Judgment to-wit:
EAST HALF OF LOT NUMBER FOUR AND WEST HALF OF LOT NUMBER THREE IN BLOCK “O”, ACCORDING TO THE PLAT OF HOBB’S ADDITION TO THE TOWN OF BLOUNTSTOWN, FLORIDA. BEING A PART OF SOUTHWEST 1/4 OF NORTHWEST 1/4 OF SECTION 28, TOWNSHIP 1 NORTH, RANGE 8 WEST, CALHOUN COUNTY, FLORIDA.
ANY PERSON CLAIMING AN INTEREST IN THE SURPLUS FROM THE SALE, IF ANY, OTHER THAN THE PROPERTY OWNER AS OF THE DATE OF THE LIS PENDENS MUST FILE A CLAIM WITHIN 60 DAYS AFTER THE SALE.
If you are a person with a disability who needs any accommodation in order to participate in this proceeding, you are entitled, at no cost to you, to the provision of certain assistance. Please contact the ADA Coordinator by mail at P.O. Box 1089, Panama City, FL 32402 at (850) 747-5338, at least seven (7) days before your scheduled court appearance, or immediately upon receiving this notification if the time before the scheduled appearance is les than seven (7) days. If you are hearing impaired, call 711.
DATED at Blountstown, Florida, on July 25, 2013.
CARLA A. HAND
As Clerk of Circuit Court
By: Lori Flowers
As Deputy Clerk
Legal Notice
NOTICE OF PUBLIC SALE
MALLORY TOWING & RECOVERY, INC. gives Notice of Foreclosure of Lien and intent to sell these vehicles on August 12, 2013, 2:00 p.m. at 18114 SR 20 W., BLOUNTSTOWN, FL 32424-4834, pursuant to subsection 713.78 of the Florida Statutes. MALLORY TOWING & RECOVERY, INC. reserves the right to accept or reject any and/or all bids.
2003 CHRYSLER
2C3HE66G63H511101
MALLORY TOWING & RECOVERY, INC.
Legal Notice
NOTICE OF PUBLIC SALE
MALLORY TOWING & RECOVERY, INC. gives Notice of Foreclosure of Lien and intent to sell these vehicles on August 12, 2013, 2:00 p.m. at 18114 SR 20 W., BLOUNTSTOWN, FL 32424-4834, pursuant to subsection 713.78 of the Florida Statutes. MALLORY TOWING & RECOVERY, INC. reserves the right to accept or reject any and/or all bids.
1991 TOYOTA
JT4RN81A3M0068779
MALLORY TOWING & RECOVERY, INC.
Legal Notice
NOTICE OF APPLICATION FOR
TAX DEED
NOTICE IS HEREBY GIVEN THAT Rose Burg is the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number and year of issuance, the description of the property, and the names in which it was assessed are as follows;
CERTIFICATE NO.541 YEAR OF 2011
DESCRIPTION OF PROPERTY
Parcel # R31-2N-10-0000-0003-1001
A part of Lot 10 of Fitzsimons unrecorded subdivision, located in the S1/2 of the N1/2 of Section 31, Township 2 North, Range 10 West, Calhoun County, Florida, more particularly described as follows: Commence at the Southwest Corner of the NW 1/4 of Section 31, Township 2 North, Range 10 West, thence run South 85 degrees 51 minutes 38 seconds East 2163.97 feet to the POINT OF BEGINNING; thence continue South 85 degrees 51 minutes 38 seconds East 200 feet; thence North 05 degrees 03 minutes 50 seconds East 100 feet; thence run North 85 degrees 51 minutes 38 seconds West 200 feet; thence run South 05 degrees 03 minutes 50 seconds West 100 feet, back to the POINT OF BEGINNING. Containing .46 acres, more or less.
NAME IN WHICH ASSESSED
George Noah
718 S. Conkling
Baltimore, MD 21224
Said property being in the County of CALHOUN, STATE OF FLORIDA. Unless such certificate shall be redeemed according to law, the property described in such certificate shall be SOLD to the highest bidder at the Courthouse door on September 5, 2013 at 10:00 A.M. CST.
By; Robie Bennett
Deputy Clerk CARLA A. HAND
Clerk of Circuit Court of
Calhoun County, Florida
Trackbacks
Trackback specific URI for this entry
No Trackbacks