Legal Notices for week of February 14, 2013
Legal Notice
CITY OF BLOUNTSTOWN NOTICE TO RECEIVE SEALED BIDS
The City of Blountstown will receive sealed bids from any qualified person, company or corporation interested in constructing:
SAM ATKINS PARK WATER
TANK REPAIRS
This project consists of the removal and replacement of all the roof panels and bolts on an existing AquaStore 100,000 gallon ground storage potable water tank. The roof consists of 33 inner ring panels and 33 outer ring panels with one manway hatch and one vent. The contractor will be required to remove and replace the aerator assembly.
Plans and specifications can be obtained from the City of Blountstown, 20591 Central Avenue Wes t, Blountstown, Florida 32424, (850) 674-5488. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
Bids will be received until 4:00 p.m.CST, on Tuesday, February 12, 2013 at Blountstown City Hall, 20591 Central Avenue West, Blountstown, Florida 32424, and will be opened and read publicly on Tuesday, February 12, 2013 as soon as possible after 6:00 p.m. CST at 17276 NW Angle St. All Bids shall be submitted in a sealed envelope clearly marked “Sealed Bid – SAM ATKINS PARK WATER TANK REPAIRS”.
Completion date for this project will be 20 calendar days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $750.00 per day.
The City of Blountstown reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of the City.
If you have any questions, please call Emory Pierce, City Manager at (850) 674 5488 or email at epierce@Blountstown.org
Legal Notice
IN THE CIRCUIT COURT OF THE 14TH JUDICIAL CIRCUIT IN AND FOR
CALHOUN COUNTY, FLORIDA
CASE NO.12-318-DR
Lorenza R. Lockhart
Petitioner
and
Kenneth Lockhart
Respondent
NOTICE OF ACTION FOR
DISSOLUTION OF MARRIAGE
(No Child or Financial Support)
TO: Kenneth Lockhart
Address: Unknown
YOU ARE NOTIFIED that an action for dissolution of marriage has been filed against you and that you are required to serve a copy of your written defenses, if any, to it on Lorenza Lockhart, whose address is 11538 NW China Dawson Rd., Bristol, FL 32321 on or before February 15, 2013, and file the original with the clerk of this Court at 20859 Central Ave., E., Room 130, Blountstown, FL 32424, before service on Petitioner or immediately thereafter. If you fail to do so, a default may be entered against you for the relief demanded in the petition.
The action is asking the court to decide how the following real or personal property should be divided: NONE
Copies of all court documents in this case, including orders, are available at the Clerk of the Circuit Court’s office. You may review these documents upon request.
You must keep the Clerk of the Circuit Court’s office notified of your current address. (You may file Notice of Current Address, Florida Supreme Court Approved Family Law form 12.915.) Future papers in this lawsuit will be mailed to the address on record at the clerk’s office.
WARNING: Rule 12.285, Florida Family Law Rules of Procedures, requires certain automatic disclosure of documents and information. Failure to comply can result in sanctions, including dismissal or striking of pleadings.
Dated this January 17, 2013
Carla A. Hand
Clerk of the Circuit Court
Legal Notice
ACCEPTING SEALED BIDS
THE BOARD OF COUNTY COMMISSIONERS OF CALHOUN COUNTY WILL BE ACCEPTING SEALED BIDS FOR THE FOLLOWING :
RESIDENTIAL WATER WELL
UNTIL 12:00 P.M. ON TUESDAY February 19, 2013 BIDS WILL BE OPENED ON February 19, 2013 AT 5:00 P.M. OR AS SOON THEREAFTER AS IS PRACTICAL.
INFORMATION MAY BE PICKED UP IN THE “SHIP” OFFICE OR THE BUILDING DEPARTMENT. FOR MORE INFORMATION YOU MAY CALL DAN CLEMONS AT 674-2571 or 674-4451
THE BOARD RESERVES THE RIGHT TO ACCEPT OR REJECT ANY OR ALL BIDS.
CALHOUN COUNTY IS /AN EQUAL OPPORTUNITY/FAIR HOUSING COUNTY
Legal Notice
IN THE CIRCUIT COURT OF THE
FOURTEENTH JUDICIAL CIRCUIT
IN AND FOR
CALHOUN COUNTY, FLORIDA
CASE NO.:11-29CC
ROGER JERKINS,
individually and d/b/a
JERKINS ROOFING, INC.
Plaintiff,
-vs-
TERRY VINCENT, and his wife,
MARILYN VINCENT,
Defendants.
NOTICE OF FORECLOSURE SALE
NOTICE IS HEREBY GIVEN pursuant to a Order dated January 4, 2013, entered in the above styled cause of the Circuit Court of the FOURTEENTH Judicial Circuit in and for CALHOUN County, Florida I will sell to the highest and best bidder for cash ON THE FRONT STEPS of the Calhoun County Courthouse, at 11:00 AM CST, on the 21st day of February, 2013 the following described property as set forth in said Order to wit:
A PARCEL OF LAND IN CALHOUN COUNTY, FLORIDA, AND BEING MORE PARTICULARLY DESCRIBED AS FOLLOWS: COMMENCING at the Southwest Corner of Section 8, Township 1 North, Range 8 West, said corner marker by a D. O. T. concrete marker as shown on the recorded R. O. W. map for Dr. Eldridge Road, 47509-2601, at the Calhoun County Courthouse, thence South 89 Degrees 32 Minutes 23 Seconds East 1286.50 feet, to the centerline of said road; thence North 0 Degrees 57 Minutes 53 Seconds West along said centerline, 1337.15 feet to the intersection of two dirt roads; thence North 0 Degrees 54 Minutes 43 Seconds West 1319.37 feet, to the POINT OF BEGINNING, said point being a set iron on the East side of Lee Farm Road at the intersection with the South line of the NW 1/2 of Section 8; thence South 89 Degrees 41 Minutes 34 Seconds East along said South line and an existing property line fence, 1111.82 feet to a set concrete marker; thence South 89 Degrees 34 Minutes 09 Seconds East along said property line fence, 1100.59 feet, to an existing concrete marker set on the line between Smith and Howell properties; thence North 0 Degrees 01 Minute 50 Seconds East along the existing property lying between Howell and Smith properties, 791.60 feet, to a set concrete marker; thence North 89 Degrees 34 Minutes 09 Seconds West 1100.59, to a set concrete marker; thence South 0 Degrees 01 Minute 50 Seconds West 761.60 feet, to a set iron; thence North 89 Degrees 41 Minutes 34 Seconds West, 1111.8 feet to the East side of Lee Farm Road; thence South 30 feet to the POINT OF BEGINNING. Said land being in the NW 1/2, lying East of the Public Road and in the West 260 yards of the W 1/2 of the NE 1/2 of Section 8, Township 1 North, Range 8 West.
Any person claiming an interest in the surplus from this sale, if any, other than the property owner as of the date of the Lis Pendens must file a claim within sixty (60) days after the sale.
DATED this 4th day of February, 2013.
CARLA HAND
CLERK OF THE COURT
Legal Notice
STATE OF FLORIDA
DEPARTMENT OF ENVIRONMENTAL PROTECTION
NOTICE OF INTENT TO ISSUE PERMIT
The Department of Environmental Protection gives notice of its intent to issue an environmental resource permit for Apalachicola River Snagging, file number 07-0129424-008-EI, to the US Army Corps of Engineers, Mobile District, at P.O. Box 2288, Mobile, Alabama 36628-0001.
The purpose of the permit is to authorize maintenance snagging (relocation of tree snags out of the navigation channel) in the Florida portion of the Apalachicola, Chattahoochee, and Flint Rivers (ACF) Federal Navigation Project.
The project will be located in the Apalachicola River between River Mile 0.0 and River Mile 106.4 in Class III, Outstanding Florida Waters (entire Florida portion of river), and Apalachicola Bay Aquatic Preserve (River Miles 0.0 – 4.5) in Jackson, Gadsden, Calhoun, Liberty, Gulf, and Franklin Counties.
Based on all the above, and with the application of general and limiting specific conditions of the permit, the Department has reasonable assurance the project, s proposed, fully meets the environmental resources permitting requirements of Chapter 62-346, Florida Administrative Code, and will not harm the environment.
A person whose substantial interests are affected by the Department’s action may petition for an administrative proceeding (hearing) under Sections 120.569 and 120.57 of the Florida Statute. The petition must contain the information set forth below and must be filed (received by the clerk) in the Office of General Counsel of the Department at 3900 Commonwealth Boulevard, Mail Station 35, Tallahassee, Florida 32399-3000.
Because the administrative hearing process is designed to re-determine final agency action on the application, the filing of a petition for an administrative hearing may result in a modification of the permit, or even a denial of the application. Accordingly, the applicant will not commence construction or other activities under this permit until the deadlines below for filing a petition for an administrative hearing, or request for an extension of time, have expired.
Under subsection 62-110.106(4) of the Florida Administrative Code, a person whose substantial interests are affected by the Department’s action may also request an extension of time to file a petition for an administrative hearing. The Department may, for good cause shown, grant the request for an extension of time. Requests for extension of time must be filed with the Office of General Counsel of the Department at 3900 Commonwealth Boulevard, Mail Station 35, Tallahassee, Florida 32399-3000, before the applicable deadline. A timely request for extension of time shall toll the running time period for filing a petition until the request is acted upon. If a request is filed late, the Department may still grant it upon a motion by the requesting party showing that the failure to file a request for an extension of time before the deadline was the result of excusable neglect.
In the event that a timely and sufficient petition for an administrative hearing is filed, other persons whose substantial interest will be affected by the outcome of the administrative process have the right to petition to intervene in the proceeding. Intervention will be only at the discretion of the presiding officer upon the filing of a motion in compliance with Rule 28-106.205 of the Florida Administrative Code.
In accordance with subsection 28-106.111(2) and subparagraph 62-110.106(3).4, Florida Administrative Code, petitions for an administrative hearing by the applicant must be filed within 14 days of receipt of written notice. Petitions filed by any persons other than the applicant, and other than those entitled to written notice under Section 120.60(3) of the Florida Statutes, must be filed within 14 days of publication of the notice.
Under Section 120.60 (3) of the Florida Statutes, however, any person who has asked the Department for notice of agency action may file a petition within 14 days of such notice, regardless of the date of publication.
The petitioner shall mail a copy of the petition to the applicant at the address indicated above at the time of filing. The failure of any person to file a petition for an administrative hearing within the appropriate time period shall constitute a waiver of those rights.
A petition that disputes the material facts on which the Department’s action is based must contain the following information:
(a) The name and address of each agency affected and each agency’s file or identification number, if known:
(b) The name, address, and telephone number of the petitioner; the name, address, and telephone of the petitioner’s representative, if any, which shall be the address for service purposes during the course of the proceeding; and an explanation of how the petitioner’s substantial interests are or will be affected by the agency determination’
(c) A statement of when and how the petitioner received notice of the agency decision;
(d) A statement of all disputed issues of material fact. If there are none, the petition must so indicate;
(e) A concise statement of the ultimate facts alleged, including the specific facts that the petitioner contends warrant reversal or modification of the agency’s proposed action;
(f) A statement of the specific rules or status that the petitioner contends require reversal or modification of the agency’s proposed action; and
(g) A statement of the relief sought by the petitioner, stating precisely the action that the petitioner wishes the agency to take with respect to the agency’s proposed action.
A petition that does not dispute the material facts on which the Department’s action is based shall state that no such facts are in dispute and otherwise shall contain the same information as set forth above, as required by Rule 28-106.301, Florida Administrative Code. Under Sections 120.569(2)(c) and (d) of the Florida Statute, a petition for administrative hearing must be dismissed by the agency if the petition does not substantially comply with the above requirements or is untimely filed.
This action is final and effective on the date filed with the Clerk of the Department unless a petition is filed in accordance with the above. Upon the timely filing of petition this order will not be effective until further order of the Department.
This permit, when issued, constitutes an order of the Department. The applicant has the right to seek judicial review of the order under Section 120.68 of the Florida Statute, by the filing of the notice of appeal under Rule 9.110 of the Florida Rules of Appellate Procedure with the Clerk of the Department in the Office of General Counsel, 3900 Commonwealth Boulevard, Mail Station 35, Tallahassee, Florida, 32399-3000; and by filing a copy of the notice of the appeal accompanied by the applicable filing fees with the appropriate district court of appeal. The notice of appeal must e filed within 30 days from the date when the final order is filed with the Clerk of the Department.
Requests for review before the Land and Water Adjudicatory Commission must be filed with the Secretary of the Commission and served on the Department within 20 days from the date when the final order is filed with the Clerk of the Department.
The application for this permit is available for public inspection during normal business hours, 8:00 a.m. to 5:00 p.m., Monday through Friday, except for legal holidays, at the Northwest District office, 160 W. Government Street, Pensacola, Florida.
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT OF FLORIDA, IN AND FOR
CALHOUN COUNTY
CIVIL DIVISION
Case No. 07-2012-CA-000016
MIDFIRST BANK
Plaintiff,
vs.
KATHY HOLLIDAY A/K/A KATHY ARROYO, UNKNOWN SPOUSE OF KATHY HOLLIDAY A/K/A KATHY C. ARROYO, AND UNKNOWN TENANTS/OWNERS,
Defendants.
NOTICE OF SALE
Notice is hereby given, pursuant to Final Judgment of Foreclosure for Plaintiff entered in this cause on February 4, 2013, in the Circuit Court of Calhoun County, Florida, I will sell the property situated in Calhoun County, Florida described as:
COMMENCE AT THE SOUTHEAST CORNER OF SECTION 32, TOWNSHIP 1 NORTH, RANGE 8 WEST, IN CALHOUN COUNTY, FLORIDA; THENC RUN NORTH 2,743.0 FEET; THENCE RUN WEST 894.9 FEET; THENCE RUN NORTH 88 DEGREES 46 MINUTES WEST 296.71 FEET TO THE POINT OF BEGINNING; THENCE CONTINUE TO RUN NORTH 88 DEGREES 46 MINUTES WEST 208.71 FEET; THENCE RUN NORTH 01 DEGREES 51 MINUTES EAST 208.71 FEET; THENCE RUN SOUTH 88 DEGREES 46 MINUTES EAST 208.71 FEET; THENCE RUN SOUTH 01 DEGREE 51 MINUTES WEST 208.71 FEET TO THE POINT OF BEGINNING. ALSO KNOWN AS LOT NO 21 OF AN UNRECORDED PLAT.
and commonly known as: 20177 SW SHERRY AVE, BLOUNTSTOWN, FL 32424; including the building, appurtenances, and fixtures located therein, at public sale, to the highest and best bidder, for cash, on April 18, 2013, at 11:00 a.m. CST.
Any persons claiming an interest in the surplus of the sale, if any, other than the property owner as of the date of the lis pendens must file a claim within 60 days after the sale.
Dated this 4th day of February, 2013.
CARLA HAND,
CLERK OF THE CIRCUIT COURT
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT IN AND FOR
CALHOUN COUNTY, FLORIDA
CIVIL ACTION
CASE NO.: 07-2012-CA-000293
REGIONS BANK D/B/A REGIONS MORTGAGE,
Plaintiff,
vs.
BARBARA MCFALLS A/K/A BARBARA ANN
MCFALLS, et al,
Defendant(s).
NOTICE OF ACTION
TO:
SHIRLEY M. JERNIGAN A/K/A SHIRLEY JERNIGAN
LAST KNOWN ADDRESS:
1400 HANCOCK BLVD.
DAYTONA BEACH, FL 32114
CURRENT ADDRESS:
UNKNOWN
ANY AND ALL UNKNOWN PARTIES CLAIMING BY, THROUGH, UNDER, AND AGAINST THE HEREIN NAMED INDIVIDUAL DEFENDANT(S) WHO ARE OT KNOWN TO BE DEAD OR ALIVE, WHETHER SAID UNKNOWN PARTIES MAY CLAIM AN INTEREST AS SPOUSES, HEIRS, DEVISEES, GRANTEES, OR OTHER CLAIMANTS
LAST KNOWN ADDRESS: UNKNOWN
CURRENT ADDRESS: UNKNOWN
YOU ARE NOTIFIED that an action to foreclose a mortgage on the following property in CALHOUN County, Florida:
COMMENCE AT A 3/4 IRON PIPE MARKING THE SOUTHWEST CORNER OF SECTION 15, TOWNSHIP 2 NORTH, RANGE 9 WEST, CALHOUN COUNTY, FLORIDA, THENCE SOUTH 89 DEGREES 09 MINUTES 27 SECONDS EAST, A DISTANCE OF 1403.87 FEET; THENCE NORTH 00 DEGREES 54 MINUTES 04 SECONDS EAST, A DISTANCE OF 528.28 FEET TO THE POINT OF BEGINNING, SAID POINT BEING ON THE WESTERLY RIGHT OF WAY LINE OF STATE ROAD NO. 71 OFFSET 35 FEET WESTERLY FROM THE CENTERLINE OF SAID ROAD. FROM SAID POINT OF BEGINNING THENCE NORTH 89 DEGREES 05 MINUTES 48 SECONDS WEST, A DISTANCE OF 105.00 FEET; THENCE NORTH 79 DEGREES 38 MINUTES 48 SECONDS WEST, A DISTANCE OF 163.46 FEET; THENCE NORTH 28 DEGREES 39 MINUTES 54 SECONDS WEST, A DISTANCE OF 85.47 FEET; THENCE NORTH 12 DEGREES 28 MINUTES 42 SECONDS WEST, A DISTANCE OF 121.93 FEET; THENCE NORTH 22 DEGREES 17 MINUTES 33 SECONDS WEST, A DISTANCE OF 62.94 FEET; THENCE NORTH 51 DEGREES 20 MINUTES 31 SECONDS WEST, A DISTANCE OF 84.11 FEET TO THE MOST SOUTHERLY LINE OF LANDS DESCRIBED IN OFFICIAL RECORDS BOOK 120 AT PAGE 566 OF THE PUBLIC RECORDS OF SAID COUNTY; THENCE ALONG THE LINES OF SAID LANDS AS FOLLOWS: THENCE SOUTH 88 DEGREES 57 MINUTES 00 SECONDS EAST, A DISTANCE OF 239.68 FEET; THENCE NORTH 01 DEGREE 03 MINUTES 00 SECONDS EAST, A DISTANCE OF 215.00 FEET; THENCE SOUTH 88 DEGREES 57 MINUTES 00 SECONDS EAST, A DISTANCE OF 82.00 FEET; THENCE NORTH 01 DEGREE 03 MINUTE 00 SECONDS EAST, A DISTANCE OF 10.00 FEET TO THE SOUTHWEST CORNER OF LANDS DESCRIBED IN OFFICIAL RECORDS BOOK 287 AT PAGE 550 OF SAID PUBLIC RECORDS; THENCE LEAVING THE AFORESAID LANDS DESCRIBED IN OFFICIAL RECORDS BOOK 1120 AT PAGE 566 RUN THENCE SOUTH 88 DEGREES 57 MINUTES 00 SECONDS EAST ALONG THE SOUTHERLY LINE OF THE AFORESAID LANDS DESCRIBED IN OFFICIAL RECORDS BOOK 287 AT PAGE 550, A DISTANCE OF 105.66 FEET TO THE AFORESAID WESTERLY RIGHT OF WAY LINE OF STATE ROAD NO. 71; THENCE SOUTH 00 DEGREES 54 MINUTES 04 SECONDS WEST, A DISTANCE OF 553.01 FEET TO THE POINT OF BEGINNING.
has been filed against you and you are required to serve a copy of your written defenses within 30 days after the first publication, if any, on Ronald R. Wolfe & Associates, P.L., Plaintiff’s attorney, whose address is 4919 Memorial Highway, Suite 200, Tampa, Florida 33634, and file the original with this Court either before service on Plaintiff’s attorney or immediately thereafter; otherwise a default will be entered against you for the relief demanded in the Complaint or petition.
This notice shall be published once each week for two consecutive weeks in the County Record.
WITNESS my hand the seal of this Court on this 4th day of February, 2013.
CARLA A. HAND,
CLERK OF COURT
The City of Blountstown will receive sealed bids from any qualified person, company or corporation interested in constructing:
SAM ATKINS PARK WATER
TANK REPAIRS
This project consists of the removal and replacement of all the roof panels and bolts on an existing AquaStore 100,000 gallon ground storage potable water tank. The roof consists of 33 inner ring panels and 33 outer ring panels with one manway hatch and one vent. The contractor will be required to remove and replace the aerator assembly.
Plans and specifications can be obtained from the City of Blountstown, 20591 Central Avenue Wes t, Blountstown, Florida 32424, (850) 674-5488. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
Bids will be received until 4:00 p.m.CST, on Tuesday, February 12, 2013 at Blountstown City Hall, 20591 Central Avenue West, Blountstown, Florida 32424, and will be opened and read publicly on Tuesday, February 12, 2013 as soon as possible after 6:00 p.m. CST at 17276 NW Angle St. All Bids shall be submitted in a sealed envelope clearly marked “Sealed Bid – SAM ATKINS PARK WATER TANK REPAIRS”.
Completion date for this project will be 20 calendar days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $750.00 per day.
The City of Blountstown reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of the City.
If you have any questions, please call Emory Pierce, City Manager at (850) 674 5488 or email at epierce@Blountstown.org
Legal Notice
IN THE CIRCUIT COURT OF THE 14TH JUDICIAL CIRCUIT IN AND FOR
CALHOUN COUNTY, FLORIDA
CASE NO.12-318-DR
Lorenza R. Lockhart
Petitioner
and
Kenneth Lockhart
Respondent
NOTICE OF ACTION FOR
DISSOLUTION OF MARRIAGE
(No Child or Financial Support)
TO: Kenneth Lockhart
Address: Unknown
YOU ARE NOTIFIED that an action for dissolution of marriage has been filed against you and that you are required to serve a copy of your written defenses, if any, to it on Lorenza Lockhart, whose address is 11538 NW China Dawson Rd., Bristol, FL 32321 on or before February 15, 2013, and file the original with the clerk of this Court at 20859 Central Ave., E., Room 130, Blountstown, FL 32424, before service on Petitioner or immediately thereafter. If you fail to do so, a default may be entered against you for the relief demanded in the petition.
The action is asking the court to decide how the following real or personal property should be divided: NONE
Copies of all court documents in this case, including orders, are available at the Clerk of the Circuit Court’s office. You may review these documents upon request.
You must keep the Clerk of the Circuit Court’s office notified of your current address. (You may file Notice of Current Address, Florida Supreme Court Approved Family Law form 12.915.) Future papers in this lawsuit will be mailed to the address on record at the clerk’s office.
WARNING: Rule 12.285, Florida Family Law Rules of Procedures, requires certain automatic disclosure of documents and information. Failure to comply can result in sanctions, including dismissal or striking of pleadings.
Dated this January 17, 2013
Carla A. Hand
Clerk of the Circuit Court
Legal Notice
ACCEPTING SEALED BIDS
THE BOARD OF COUNTY COMMISSIONERS OF CALHOUN COUNTY WILL BE ACCEPTING SEALED BIDS FOR THE FOLLOWING :
RESIDENTIAL WATER WELL
UNTIL 12:00 P.M. ON TUESDAY February 19, 2013 BIDS WILL BE OPENED ON February 19, 2013 AT 5:00 P.M. OR AS SOON THEREAFTER AS IS PRACTICAL.
INFORMATION MAY BE PICKED UP IN THE “SHIP” OFFICE OR THE BUILDING DEPARTMENT. FOR MORE INFORMATION YOU MAY CALL DAN CLEMONS AT 674-2571 or 674-4451
THE BOARD RESERVES THE RIGHT TO ACCEPT OR REJECT ANY OR ALL BIDS.
CALHOUN COUNTY IS /AN EQUAL OPPORTUNITY/FAIR HOUSING COUNTY
Legal Notice
IN THE CIRCUIT COURT OF THE
FOURTEENTH JUDICIAL CIRCUIT
IN AND FOR
CALHOUN COUNTY, FLORIDA
CASE NO.:11-29CC
ROGER JERKINS,
individually and d/b/a
JERKINS ROOFING, INC.
Plaintiff,
-vs-
TERRY VINCENT, and his wife,
MARILYN VINCENT,
Defendants.
NOTICE OF FORECLOSURE SALE
NOTICE IS HEREBY GIVEN pursuant to a Order dated January 4, 2013, entered in the above styled cause of the Circuit Court of the FOURTEENTH Judicial Circuit in and for CALHOUN County, Florida I will sell to the highest and best bidder for cash ON THE FRONT STEPS of the Calhoun County Courthouse, at 11:00 AM CST, on the 21st day of February, 2013 the following described property as set forth in said Order to wit:
A PARCEL OF LAND IN CALHOUN COUNTY, FLORIDA, AND BEING MORE PARTICULARLY DESCRIBED AS FOLLOWS: COMMENCING at the Southwest Corner of Section 8, Township 1 North, Range 8 West, said corner marker by a D. O. T. concrete marker as shown on the recorded R. O. W. map for Dr. Eldridge Road, 47509-2601, at the Calhoun County Courthouse, thence South 89 Degrees 32 Minutes 23 Seconds East 1286.50 feet, to the centerline of said road; thence North 0 Degrees 57 Minutes 53 Seconds West along said centerline, 1337.15 feet to the intersection of two dirt roads; thence North 0 Degrees 54 Minutes 43 Seconds West 1319.37 feet, to the POINT OF BEGINNING, said point being a set iron on the East side of Lee Farm Road at the intersection with the South line of the NW 1/2 of Section 8; thence South 89 Degrees 41 Minutes 34 Seconds East along said South line and an existing property line fence, 1111.82 feet to a set concrete marker; thence South 89 Degrees 34 Minutes 09 Seconds East along said property line fence, 1100.59 feet, to an existing concrete marker set on the line between Smith and Howell properties; thence North 0 Degrees 01 Minute 50 Seconds East along the existing property lying between Howell and Smith properties, 791.60 feet, to a set concrete marker; thence North 89 Degrees 34 Minutes 09 Seconds West 1100.59, to a set concrete marker; thence South 0 Degrees 01 Minute 50 Seconds West 761.60 feet, to a set iron; thence North 89 Degrees 41 Minutes 34 Seconds West, 1111.8 feet to the East side of Lee Farm Road; thence South 30 feet to the POINT OF BEGINNING. Said land being in the NW 1/2, lying East of the Public Road and in the West 260 yards of the W 1/2 of the NE 1/2 of Section 8, Township 1 North, Range 8 West.
Any person claiming an interest in the surplus from this sale, if any, other than the property owner as of the date of the Lis Pendens must file a claim within sixty (60) days after the sale.
DATED this 4th day of February, 2013.
CARLA HAND
CLERK OF THE COURT
Legal Notice
STATE OF FLORIDA
DEPARTMENT OF ENVIRONMENTAL PROTECTION
NOTICE OF INTENT TO ISSUE PERMIT
The Department of Environmental Protection gives notice of its intent to issue an environmental resource permit for Apalachicola River Snagging, file number 07-0129424-008-EI, to the US Army Corps of Engineers, Mobile District, at P.O. Box 2288, Mobile, Alabama 36628-0001.
The purpose of the permit is to authorize maintenance snagging (relocation of tree snags out of the navigation channel) in the Florida portion of the Apalachicola, Chattahoochee, and Flint Rivers (ACF) Federal Navigation Project.
The project will be located in the Apalachicola River between River Mile 0.0 and River Mile 106.4 in Class III, Outstanding Florida Waters (entire Florida portion of river), and Apalachicola Bay Aquatic Preserve (River Miles 0.0 – 4.5) in Jackson, Gadsden, Calhoun, Liberty, Gulf, and Franklin Counties.
Based on all the above, and with the application of general and limiting specific conditions of the permit, the Department has reasonable assurance the project, s proposed, fully meets the environmental resources permitting requirements of Chapter 62-346, Florida Administrative Code, and will not harm the environment.
A person whose substantial interests are affected by the Department’s action may petition for an administrative proceeding (hearing) under Sections 120.569 and 120.57 of the Florida Statute. The petition must contain the information set forth below and must be filed (received by the clerk) in the Office of General Counsel of the Department at 3900 Commonwealth Boulevard, Mail Station 35, Tallahassee, Florida 32399-3000.
Because the administrative hearing process is designed to re-determine final agency action on the application, the filing of a petition for an administrative hearing may result in a modification of the permit, or even a denial of the application. Accordingly, the applicant will not commence construction or other activities under this permit until the deadlines below for filing a petition for an administrative hearing, or request for an extension of time, have expired.
Under subsection 62-110.106(4) of the Florida Administrative Code, a person whose substantial interests are affected by the Department’s action may also request an extension of time to file a petition for an administrative hearing. The Department may, for good cause shown, grant the request for an extension of time. Requests for extension of time must be filed with the Office of General Counsel of the Department at 3900 Commonwealth Boulevard, Mail Station 35, Tallahassee, Florida 32399-3000, before the applicable deadline. A timely request for extension of time shall toll the running time period for filing a petition until the request is acted upon. If a request is filed late, the Department may still grant it upon a motion by the requesting party showing that the failure to file a request for an extension of time before the deadline was the result of excusable neglect.
In the event that a timely and sufficient petition for an administrative hearing is filed, other persons whose substantial interest will be affected by the outcome of the administrative process have the right to petition to intervene in the proceeding. Intervention will be only at the discretion of the presiding officer upon the filing of a motion in compliance with Rule 28-106.205 of the Florida Administrative Code.
In accordance with subsection 28-106.111(2) and subparagraph 62-110.106(3).4, Florida Administrative Code, petitions for an administrative hearing by the applicant must be filed within 14 days of receipt of written notice. Petitions filed by any persons other than the applicant, and other than those entitled to written notice under Section 120.60(3) of the Florida Statutes, must be filed within 14 days of publication of the notice.
Under Section 120.60 (3) of the Florida Statutes, however, any person who has asked the Department for notice of agency action may file a petition within 14 days of such notice, regardless of the date of publication.
The petitioner shall mail a copy of the petition to the applicant at the address indicated above at the time of filing. The failure of any person to file a petition for an administrative hearing within the appropriate time period shall constitute a waiver of those rights.
A petition that disputes the material facts on which the Department’s action is based must contain the following information:
(a) The name and address of each agency affected and each agency’s file or identification number, if known:
(b) The name, address, and telephone number of the petitioner; the name, address, and telephone of the petitioner’s representative, if any, which shall be the address for service purposes during the course of the proceeding; and an explanation of how the petitioner’s substantial interests are or will be affected by the agency determination’
(c) A statement of when and how the petitioner received notice of the agency decision;
(d) A statement of all disputed issues of material fact. If there are none, the petition must so indicate;
(e) A concise statement of the ultimate facts alleged, including the specific facts that the petitioner contends warrant reversal or modification of the agency’s proposed action;
(f) A statement of the specific rules or status that the petitioner contends require reversal or modification of the agency’s proposed action; and
(g) A statement of the relief sought by the petitioner, stating precisely the action that the petitioner wishes the agency to take with respect to the agency’s proposed action.
A petition that does not dispute the material facts on which the Department’s action is based shall state that no such facts are in dispute and otherwise shall contain the same information as set forth above, as required by Rule 28-106.301, Florida Administrative Code. Under Sections 120.569(2)(c) and (d) of the Florida Statute, a petition for administrative hearing must be dismissed by the agency if the petition does not substantially comply with the above requirements or is untimely filed.
This action is final and effective on the date filed with the Clerk of the Department unless a petition is filed in accordance with the above. Upon the timely filing of petition this order will not be effective until further order of the Department.
This permit, when issued, constitutes an order of the Department. The applicant has the right to seek judicial review of the order under Section 120.68 of the Florida Statute, by the filing of the notice of appeal under Rule 9.110 of the Florida Rules of Appellate Procedure with the Clerk of the Department in the Office of General Counsel, 3900 Commonwealth Boulevard, Mail Station 35, Tallahassee, Florida, 32399-3000; and by filing a copy of the notice of the appeal accompanied by the applicable filing fees with the appropriate district court of appeal. The notice of appeal must e filed within 30 days from the date when the final order is filed with the Clerk of the Department.
Requests for review before the Land and Water Adjudicatory Commission must be filed with the Secretary of the Commission and served on the Department within 20 days from the date when the final order is filed with the Clerk of the Department.
The application for this permit is available for public inspection during normal business hours, 8:00 a.m. to 5:00 p.m., Monday through Friday, except for legal holidays, at the Northwest District office, 160 W. Government Street, Pensacola, Florida.
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT OF FLORIDA, IN AND FOR
CALHOUN COUNTY
CIVIL DIVISION
Case No. 07-2012-CA-000016
MIDFIRST BANK
Plaintiff,
vs.
KATHY HOLLIDAY A/K/A KATHY ARROYO, UNKNOWN SPOUSE OF KATHY HOLLIDAY A/K/A KATHY C. ARROYO, AND UNKNOWN TENANTS/OWNERS,
Defendants.
NOTICE OF SALE
Notice is hereby given, pursuant to Final Judgment of Foreclosure for Plaintiff entered in this cause on February 4, 2013, in the Circuit Court of Calhoun County, Florida, I will sell the property situated in Calhoun County, Florida described as:
COMMENCE AT THE SOUTHEAST CORNER OF SECTION 32, TOWNSHIP 1 NORTH, RANGE 8 WEST, IN CALHOUN COUNTY, FLORIDA; THENC RUN NORTH 2,743.0 FEET; THENCE RUN WEST 894.9 FEET; THENCE RUN NORTH 88 DEGREES 46 MINUTES WEST 296.71 FEET TO THE POINT OF BEGINNING; THENCE CONTINUE TO RUN NORTH 88 DEGREES 46 MINUTES WEST 208.71 FEET; THENCE RUN NORTH 01 DEGREES 51 MINUTES EAST 208.71 FEET; THENCE RUN SOUTH 88 DEGREES 46 MINUTES EAST 208.71 FEET; THENCE RUN SOUTH 01 DEGREE 51 MINUTES WEST 208.71 FEET TO THE POINT OF BEGINNING. ALSO KNOWN AS LOT NO 21 OF AN UNRECORDED PLAT.
and commonly known as: 20177 SW SHERRY AVE, BLOUNTSTOWN, FL 32424; including the building, appurtenances, and fixtures located therein, at public sale, to the highest and best bidder, for cash, on April 18, 2013, at 11:00 a.m. CST.
Any persons claiming an interest in the surplus of the sale, if any, other than the property owner as of the date of the lis pendens must file a claim within 60 days after the sale.
Dated this 4th day of February, 2013.
CARLA HAND,
CLERK OF THE CIRCUIT COURT
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT IN AND FOR
CALHOUN COUNTY, FLORIDA
CIVIL ACTION
CASE NO.: 07-2012-CA-000293
REGIONS BANK D/B/A REGIONS MORTGAGE,
Plaintiff,
vs.
BARBARA MCFALLS A/K/A BARBARA ANN
MCFALLS, et al,
Defendant(s).
NOTICE OF ACTION
TO:
SHIRLEY M. JERNIGAN A/K/A SHIRLEY JERNIGAN
LAST KNOWN ADDRESS:
1400 HANCOCK BLVD.
DAYTONA BEACH, FL 32114
CURRENT ADDRESS:
UNKNOWN
ANY AND ALL UNKNOWN PARTIES CLAIMING BY, THROUGH, UNDER, AND AGAINST THE HEREIN NAMED INDIVIDUAL DEFENDANT(S) WHO ARE OT KNOWN TO BE DEAD OR ALIVE, WHETHER SAID UNKNOWN PARTIES MAY CLAIM AN INTEREST AS SPOUSES, HEIRS, DEVISEES, GRANTEES, OR OTHER CLAIMANTS
LAST KNOWN ADDRESS: UNKNOWN
CURRENT ADDRESS: UNKNOWN
YOU ARE NOTIFIED that an action to foreclose a mortgage on the following property in CALHOUN County, Florida:
COMMENCE AT A 3/4 IRON PIPE MARKING THE SOUTHWEST CORNER OF SECTION 15, TOWNSHIP 2 NORTH, RANGE 9 WEST, CALHOUN COUNTY, FLORIDA, THENCE SOUTH 89 DEGREES 09 MINUTES 27 SECONDS EAST, A DISTANCE OF 1403.87 FEET; THENCE NORTH 00 DEGREES 54 MINUTES 04 SECONDS EAST, A DISTANCE OF 528.28 FEET TO THE POINT OF BEGINNING, SAID POINT BEING ON THE WESTERLY RIGHT OF WAY LINE OF STATE ROAD NO. 71 OFFSET 35 FEET WESTERLY FROM THE CENTERLINE OF SAID ROAD. FROM SAID POINT OF BEGINNING THENCE NORTH 89 DEGREES 05 MINUTES 48 SECONDS WEST, A DISTANCE OF 105.00 FEET; THENCE NORTH 79 DEGREES 38 MINUTES 48 SECONDS WEST, A DISTANCE OF 163.46 FEET; THENCE NORTH 28 DEGREES 39 MINUTES 54 SECONDS WEST, A DISTANCE OF 85.47 FEET; THENCE NORTH 12 DEGREES 28 MINUTES 42 SECONDS WEST, A DISTANCE OF 121.93 FEET; THENCE NORTH 22 DEGREES 17 MINUTES 33 SECONDS WEST, A DISTANCE OF 62.94 FEET; THENCE NORTH 51 DEGREES 20 MINUTES 31 SECONDS WEST, A DISTANCE OF 84.11 FEET TO THE MOST SOUTHERLY LINE OF LANDS DESCRIBED IN OFFICIAL RECORDS BOOK 120 AT PAGE 566 OF THE PUBLIC RECORDS OF SAID COUNTY; THENCE ALONG THE LINES OF SAID LANDS AS FOLLOWS: THENCE SOUTH 88 DEGREES 57 MINUTES 00 SECONDS EAST, A DISTANCE OF 239.68 FEET; THENCE NORTH 01 DEGREE 03 MINUTES 00 SECONDS EAST, A DISTANCE OF 215.00 FEET; THENCE SOUTH 88 DEGREES 57 MINUTES 00 SECONDS EAST, A DISTANCE OF 82.00 FEET; THENCE NORTH 01 DEGREE 03 MINUTE 00 SECONDS EAST, A DISTANCE OF 10.00 FEET TO THE SOUTHWEST CORNER OF LANDS DESCRIBED IN OFFICIAL RECORDS BOOK 287 AT PAGE 550 OF SAID PUBLIC RECORDS; THENCE LEAVING THE AFORESAID LANDS DESCRIBED IN OFFICIAL RECORDS BOOK 1120 AT PAGE 566 RUN THENCE SOUTH 88 DEGREES 57 MINUTES 00 SECONDS EAST ALONG THE SOUTHERLY LINE OF THE AFORESAID LANDS DESCRIBED IN OFFICIAL RECORDS BOOK 287 AT PAGE 550, A DISTANCE OF 105.66 FEET TO THE AFORESAID WESTERLY RIGHT OF WAY LINE OF STATE ROAD NO. 71; THENCE SOUTH 00 DEGREES 54 MINUTES 04 SECONDS WEST, A DISTANCE OF 553.01 FEET TO THE POINT OF BEGINNING.
has been filed against you and you are required to serve a copy of your written defenses within 30 days after the first publication, if any, on Ronald R. Wolfe & Associates, P.L., Plaintiff’s attorney, whose address is 4919 Memorial Highway, Suite 200, Tampa, Florida 33634, and file the original with this Court either before service on Plaintiff’s attorney or immediately thereafter; otherwise a default will be entered against you for the relief demanded in the Complaint or petition.
This notice shall be published once each week for two consecutive weeks in the County Record.
WITNESS my hand the seal of this Court on this 4th day of February, 2013.
CARLA A. HAND,
CLERK OF COURT
Trackbacks
Trackback specific URI for this entry
No Trackbacks