Legal Notice
Legals for 01-31-13
CITY OF BLOUNTSTOWN NOTICE TO RECEIVE SEALED BIDS
The City of Blountstown will receive sealed bids from any qualified person, company or corporation interested in constructing:
SAM ATKINS PAR
WATER TANK REPAIRS
This project consists of the removal and replacement of all the roof panels and bolts on an existing AquaStore 100,000 gallon ground storage potable water tank. The roof consists of 33 inner ring panels and 33 outer ring panels with one manway hatch and one vent. The contractor will be required to remove and replace the aerator assembly.
Plans and specifications can be obtained from the City of Blountstown, 20591 Central Avenue Wes t, Blountstown, Florida 32424, (850) 674-5488. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
Bids will be received until 4:00 p.m.CST, on Tuesday, February 12, 2013 at Blountstown City Hall, 20591 Central Avenue West, Blountstown, Florida 32424, and will be opened and read publicly on Tuesday, February 12, 2013 as soon as possible after 6:00 p.m. CST at 17276 NW Angle St. All Bids shall be submitted in a sealed envelope clearly marked “Sealed Bid – SAM ATKINS PARK WATER TANK REPAIRS”.
Completion date for this project will be 20 calendar days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $750.00 per day.
The City of Blountstown reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of the City.
If you have any questions, please call Emory Pierce, City Manager at (850) 674 5488 or email at epierce@Blountstown.org
Legal Notice
IN THE CIRCUIT COURT FOR
CALHOUN COUNTY, FLORIDA
PROBATE DIVISION
File No: 12-54PR
IN RE: ESTATE OF: SAM BAKER, JR., a/k/a
SAM BOBBY BAKER, JR.
Deceased. NOTICE OF ADMINISTRATION AND NOTICE TO CREDITORS
TO ALL PERSONS HAVING CLAIMS OR DEMANDS AGAINST THE ABOVE ESTATE AND ALL OTHER PERSONS INTERESTED IN THE ESTATE:
YOU ARE NOTIFIED that the administration of the Estate of Sam Baker, Jr., a/k/a Sam Bobby Baker, Jr., File Number 2012-54PR is pending in the Circuit Court for Calhoun County, Florida, Probate Division, 20859 Central Avenue, Blountstown, Florida 32424, the address of which is the Calhoun County Courthouse. The Personal Representative of the Estate is Tony Robinson. The name and address of the Personal Representative’s attorney is set forth below.
All persons having claims or demands against the Estate are required, WITHIN THREE MONTHS FROM THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE, to file with the Clerk of the above Court a written statement of any claim or demand they may have. Each claim must be in writing and must indicate the basis for the claim, the name and address of the creditor or his agent or attorney and the amount the claim is contingent or unliquidated, the nature of the uncertainty shall be stated. If the claim is secured, the security shall be described. The claimant shall deliver sufficient copies of the claim to the Clerk to enable the Clerk to mail one copy to the Personal Representative. All persons interested in the Estate to whom a copy of this Notice of Administration has been mailed are required, WITHIN THREE MONTHS FROM THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE, to file any objection they may have, or the qualifications of the Personal Representative, or the venue or jurisdiction of the Court.
DATED THIS 15h day January, 2013.
JAMEL BAKER
192 Delores Ln.
Midway, FL 32343
BY: J. DAVID HOUSE, P.A. J. DAVID HOUSE
16865 SE RIVER STREET
BLOUNTSTOWN, FL 32424 (850)674-5481 FLORIDA BAR #282359
COUNSEL FOR PERSONAL REP.
Legal Notice
NOTICE OF DISPOSAL
M & W SELF STORAGE RENTALS will dispose of contents of the following units on Friday, February 1, 2013 at 3:00 p.m. If not paid in full and emptied out. The unit is believed to contain household and/or personal property.
Richard Coulliette - Unit 23 South
Sheryl Taube - Unit 26 South
Josh Going - Units 35 North & 40 North
Legal Notice
IN THE CIRCUIT COURT OF THE
FOURTEENTH JUDICIAL CIRCUIT,
IN AND FOR
CALHOUN COUNTY, FLORIDA
CASE NO: 12-267CA
VANDERBILT MORTGAGE AND FINANCE, INC.
a Tennessee Corporation
P.O. Box 9800
Maryville, Tennessee 37802,
Plaintiff,
v.
MARTINE MILLS,
ANDRA D. PETERSON,
THE UNKNOWN SPOUSE OF TYRONE MILLS, and
THE UNKNOWN SPOUSE OF PURCELL SATTERWHITE
N/K/A ROBERT SATTERWHITE,
Defendants.
NOTICE OF ACTION
TO: THE UNKNOWN SPOUSE OF TYRONE MILLS:
YOU ARE NOTIFIED that a civil action has been filed against you in the Circuit Court of County of Calhoun, State of Florida, to foreclose certain real property described as follows:
SEE EXHIBIT “A”; TOGETHER WITH THAT CERTAIN 2009 CMH BLUE RIDGE MOBILE HOME, SERIAL NUMBER CLM089809TN.
Commonly known as: 27962 ST. ROSE ROAD, GRAND RIDGE, FL 32442.
You are required to file a written response with the Court and serve a copy of your written defenses, if any, to it on Timothy D. Padgett, Plaintiff’s attorney, whose address is 2878 Remington Green Circle, Tallahassee, Florida 32308, at least thirty (30) days from the date of first publication, and file the original with the clerk of this court either before service on Plaintiff’s attorney or immediately thereafter; otherwise, a default will be entered against you for the relief demanded in the complaint.
Dated this 4th day of December, 2012.
CLERK OF THE COURT
CARLA A. HAND
Legal Notice
IN THE CIRCUIT COURT OF THE 14TH JUDICIAL CIRCUIT IN AND FOR CALHOUN COUNTY, FLORIDA
CASE NO.12-318-DR
Lorenza R. Lockhart
Petitioner
and
Kenneth Lockhart
Respondent
NOTICE OF ACTION FOR
DISSOLUTION OF MARRIAGE
(No Child or Financial Support)
TO: Kenneth Lockhart
Address: Unknown
YOU ARE NOTIFIED that an action for dissolution of marriage has been filed against you and that you are required to serve a copy of your written defenses, if any, to it on Lorenza Lockhart, whose address is 11538 NW China Dawson Rd., Bristol, FL 32321 on or before February 15, 2013, and file the original with the clerk of this Court at 20859 Central Ave., E., Room 130, Blountstown, FL 32424, before service on Petitioner or immediately thereafter. If you fail to do so, a default may be entered against you for the relief demanded in the petition.
The action is asking the court to decide how the following real or personal property should be divided: NONE
Copies of all court documents in this case, including orders, are available at the Clerk of the Circuit Court’s office. You may review these documents upon request.
You must keep the Clerk of the Circuit Court’s office notified of your current address. (You may file Notice of Current Address, Florida Supreme Court Approved Family Law form 12.915.) Future papers in this lawsuit will be mailed to the address on record at the clerk’s office.
WARNING: Rule 12.285, Florida Family Law Rules of Procedures, requires certain automatic disclosure of documents and information. Failure to comply can result in sanctions, including dismissal or striking of pleadings.
Dated this January 17, 2013
Carla A. Hand
Clerk of the Circuit Court
Legal Notice
IN THE CIRCUIT COURT OF THE
FOURTEENTH JUDICIAL CIRCUIT
IN AND FOR
CALHOUN COUNTY, FLORIDA
CASE NO. 07-07-2012-CA-000048
THE BANK OF NEW YORK MELLON
FKA THE BANK OF NEW YORK,
AS TRUSTEE FOR THE CERTIFICATEHOLDERS,
CWABS, INC., ASSET-BACKED
CERTIFICATES SERIES 2007-6
Plaintiff(s),
vs.
SAMMIE STEPHENS; et al.,
Defendant
NOTICE OF SALE
PURSUANT TO CHAPTER 45
NOTICE IS HEREBY GIVEN pursuant to an Order or Final Judgment of Foreclosure dated January 18, 2013, and entered in Case No. 07-2012-CA-000048 of the Circuit Court of the 14TH Judicial Circuit in and for CALHOUN County, Florida, wherein THE BANK OF NEW YORK MELLON FKA THE BANK OF NEW YORK, AS TRUSTEE FOR THE CERTIFICATEHOLDERS, CWABS, INC. ASSET-BACKED CERTIFICATES SERIES 2007-6 is the Plaintiff and SAMMIE R. STEPHENS AND LORI A. STEPHENS are the Defendants, I will sell to the highest and best bidder for cash are held on the front steps of the Calhoun County Courthouse, 20859 Central Avenue East, Blountstown, Florida 32424, at 11:00 a.m. CST on the 25th day of April, 2013, the following described property as set forth in said Order of Final Judgment, to wit:
EAST 1/2 OF NORTHWEST 1/4 OF NORTHEAST 1/4 OF NORTHWEST 1/4, SECTION 22, TOWNSHIP 2 NORTH, RANGE 10 WEST, CALHOUN COUNTY, FLORIDA
and commonly known as 9830 INDIAN PASS RD, ALTHA, FL 32421
IF YOU ARE A PERSON CLAIMING A RIGHT TO FUNDS REMAINING AFTER THE SALE, YOU MUST FILE A CLAIM WITH THE CLERK OF COURT NO LATER THAN 60 DAYS AFTER THE SALE. IF YOU FAIL TO FILE A CLAIM, YOU WILL NOT BE ENTITLED TO ANY REMAINING FUNDS. AFTER 60 DAYS, ONLY THE OWNER OF RECORD AS OF THE DATE OF THE LIS PENDENS MAY CLAIM THE SURPLUS.
DATED at CALHOUN County, Florida, this 18th day of January, 2013.
CARLA A. HAND, Clerk
CALHOUN County, Florida
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT
IN AND FOR
CALHOUN COUNTY, FLORIDA
2011-CA-000255
Trustmark National Bank
Plaintiff,
-vs-
Rudolph L. McLeod, III a/k/a Rudolph L.
McLeod and Amy N. McLeod, Husband and
Wife; Sun Trust Bank
Defendant(s).
NOTICE OF SALE
NOTICE IS HEREBY GIVEN pursuant to an Order of Final Judgment of Foreclosure January 15, 2013, entered in Civil Case Number 2011-CA-000255 of the Circuit Court of the 14th Judicial Circuit in and for Calhoun County, Florida, wherein Trustmark National Bank, Plaintiff and Rudolph L. McLeod, III a/k/a Rudolph L. McLeod and Army N. McLeod, Husband and Wife are defendants, I, Clerk of Court, CARLA A. HAND, will sell to the highest and best bidder for cash of the FRONT STEPS OF THE CALHOUN COUNTY COURTHOUSE at 20859 CENTRAL AVE. EAST, BLOUNTSTOWN, FL 32424 at 11:00 A.M. CENTRAL STANDARD TIME on March 28, 2013, the following described property as set forth in said Final Judgment, to-wit:
COMMENCE AT THE SOUTHWEST CORNER OF NORTH HALF OF LOT 2, FRACTIONAL SECTION 12, TOWNSHIP 3 SOUTH, RANGE 10 WEST, CALHOUN COUNTY, FLORIDA, AND RUN THENCE SOUTH 89 DEGREES 54 MINUTES 25 SECONDS EAST, A DISTANCE OF 1007.00 FEET, TO THE POINT OF BEGINNING. FROM SAID POINT OF BEGINNING, THENCE RUN NORTH 00 DEGREES 05 MINUTES 35 SECONDS EAST, A DISTANCE OF 120.00 FEET, THENCE NORTH 89 DEGREES 54 MINUTES 25 SECONDS WEST, A DISTANCE OF 30.00 FEET, THENCE NORTH 00 DEGREES 05 MINUTES 35 SECONDS EAST, A DISTANCE OF 100.00 FEET, THENCE NORTH 89 DEGREES 54 MINUTES 25 SECONDS WEST, A DISTANCE OF 105.00 FEET, THENCE NORTH 00 DEGREES 05 MINUTES 35 SECONDS EAST, A DISTANCE OF 235.00 FEET, THENCE SOUTH 89 DEGREES 54 MINUTES 25 SECONDS EAST, A DISTANCE OF 305.00 FEET, TO THE WESTERLY RIGHT OF WAY BOUNDARY OF RICHARDS STREET (30 FOOT RIGHT OF WAY), THENCE SOUTH 00 DEGREES 05 MINUTES 35 SECONDS WEST, ALONG SAID WESTERLY RIGHT OF WAY BOUNDARY, A DISTANCE OF 455.00 FEET, TO THE INTERSECTION OF SAID WESTERLY RIGHT T OF WAY BOUNDARY WITH THE NORTHERLY RIGHT OF WAY BOUNDARY OF OAK GROVE ROAD, THENCE NORTH 89 DEGREES 54 MINUTES 25 SECONDS WEST, A DISTANCE OF 170.00 FEET, TO THE POINT OF BEGINNING.
ANY PERSON CLAIMING AN INTEREST IN THE SURPLUS FROM THE SALE, IF ANY, OTHER THAN THE PROPERTY OWNER AS OF THE DATE OF THE LIS PENDENS MUST FILE A CLAIM WITHIN 60 DAYS AFTER THE SALE.
CARLA A. HAND
Clerk of the Circuit Court
Legal Notice
IN THE CIRCUIT COURT OF THE
14TH JUDICIAL CIRCUIT
IN AND FOR
CALHOUN COUNTY, FLORIDA
CASE NO. 07-2009-CA-000350
PNC BANK, NATIONAL ASSOCIATION
Plaintiff,
vs.
LANA K. HATHAWAY; et al.
Defendant(s)
NOTICE OF ACTION-
FORECLOSURE PROCEEDINGS
TO: DEBORAH HATHAWAY,
including any unknown spouse of the Defendant, if remarried and if said Defendant is dead his/her respective unknown spouse, heirs, devisees, grantees, assignees, creditors, lien holders, and trustees, and all other persons claiming by, through, under or against the named Defendant; and the aforementioned named Defendant and such of the aforementioned unknown Defendant and such of the unknown named Defendant as may be infants, incompetents, or otherwise not sui juris.
YOU ARE HEREBY NOTIFIED that an action to foreclose a mortgage on the following described property, to-wit:
Begin at the Northeast corner of the East Quarter of the Southwest Quarter of the Northeast Quarter of Section 30, township 2 North, Range 11 West of Calhoun County, Florida; thence run South 00°04’10” East, along the East line of the East Quarter of the Southwest Quarter of the Northeast Quarter, 1,325.39 feet; thence departing said East line on a bearing of South 89°56’23” West, 664.12 feet; thence north 00°04’10” West, 620.89 feet to a point on the centerline of Chammbry Road; thence South 85°53’09” East, along said centerline, 30.70 feet to a point and call this point “A”; thence meander Easterly and Northerly along said centerline so as to reach a point being North 56°36’13” East and 48.03 feet from aforesaid point “A”; thence run North 04°30’03” West, along aforesaid centerline, 680.18 feet; thence departing said centerline on a bearing of North 89°56’23” East 643.84 feet to the point of beginning Subject to East 30 feet for right of way of Chammbry Road.
ACCESS HAS NOT BEEN DETERMINED - POSSIBILITY OF NO ACCESS
More commonly known as 24219 NW Chammbry Ln, Fountain, FL 32438
This action has been filed against you, and you are required to serve a copy of your written defense, if any, to it on Plaintiff’s attorney, Weltman, Weinberg & Reis, Co., L.P.A., whose address is 550 West Cypress Creek Road, Suite 550, Fort Lauderdale, FL 33309, on or before 30 days after date of first publication, January 23, 2013, and file the original with the Clerk of the Circuit Court either before service on Plaintiff’s attorney or immediately thereafter; otherwise a default will be entered against you for the relief demanded in the Complaint.
Witness my hand and seal of this Court on the 18th day of January, 2013.
Carla A. Hand
Clerk of Circuit Court
Legal Notice
BID NOTICE
STATE HOUSING INITIATIVES
“SHIP PROGRAM”
The Calhoun Board of County Commissioners will accept sealed bids on behalf of its State Housing Initiatives Partnership “SHIP” Program for the rehabilitation on houses until 12:00 p.m. local time on Tuesday, February 19, 2012. Bids may be delivered to the Clerk’s Office in the Calhoun County Courthouse, Blountstown, Florida 32424. Bids must arrive before deadline. Bids will be opened at 5:00 p.m. or as soon afterwards as possible. Bids must be sealed in an envelope marked “sealed bid for ship rehab” and identified by the name of the firm, and the date and time of the bid opening.
A mandatory pre-bid conference will be held on Tuesday, February 12, 2012, at 9:00 a.m. local time in room 117 in the Calhoun County Building Department located on the 1st floor of the Calhoun County Courthouse. Bid sheets and specifications will be available at the meeting. It is the responsibility of the contractor to purchase all permits deemed necessary. Bidders must provide proof of general liability and workman’s compensation insurance in the bid package. The insurance must be in force at the time of the bid opening. As an alternative to providing workman’s compensation insurance, the prospective bidder shall provide proof of worker’s compensation exemption. Any person claiming to be exempt shall be subject to an on-the-job inspection for proof of exemption and license of all workers on job site.
Minority contractors are encouraged to participate. Calhoun County is an equal opportunity jurisdiction. The Calhoun County Board of County Commissioners reserves the right to reject any and all bids and to waive any informality. The signing of the contract is contingent upon the approval of and/or release of funds by the Florida housing finance agency.
CALHOUN COUNTY IS /AN EQUAL OPPORTUNITY/FAIR HOUSING COUNTY.
Legal Notice
ACCEPTING SEALED BIDS
THE BOARD OF COUNTY COMMISSIONERS OF CALHOUN COUNTY WILL BE ACCEPTING SEALED BIDS FOR RESIDENTIAL SEPTIC SYSTEMS ON TUESDAY, February 19, 2013. BIDS MUST BE TURNED IN TO THE CALHOUN COUNTY CLERK’S OFFICE BY 12:00 P.M. AND WILL BE OPENED AT 5:00 P.M. OR AS SOON THEREAFTER AS IS PRACTICAL.
SPECIFICATIONS MAY BE PICKED UP IN THE “SHIP” OFFICE. FOR MORE INFORMATION YOU MAY CALL DAN CLEMONS AT 674-2571 or 674-4551
THE BOARD RESERVES THE RIGHT TO ACCEPT OR REJECT ANY OR ALL BIDS.
CALHOUN COUNTY IS /AN EQUAL OPPORTUNITY/FAIR HOUSING COUNTY
Legal Notice
IN THE CIRCUIT COURT FOR
CALHOUN COUNTY, FLORIDA
PROBATE DIVISION
File No: 13-02PR
IN RE: ESTATE OF:
RHONDA FAYE HINRICHS,
Deceased.
NOTICE OF ADMINISTRATION AND
NOTICE TO CREDITORS
TO ALL PERSONS HAVING CLAIMS OR DEMANDS AGAINST THE ABOVE ESTATE AND ALL OTHER PERSONS INTERESTED IN THE ESTATE:
YOU ARE NOTIFIED that the administration of the Estate of Rhonda Faye Hinrichs, File Number 2013-02PR is pending in the Circuit Court for Calhoun County, Florida, Probate Division, 20859 Central Avenue, Blountstown, Florida 32424, the address of which is the Calhoun County Courthouse. The Personal Representative of the Estate is Marlin Hinrichs. The name and address of the Personal Representative’s attorney is set forth below.
All persons having claims or demands against the Estate are required, WITHIN THREE MONTHS FROM THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE, to file with the Clerk of the above Court a written statement of any claim or demand they may have. Each claim must be in writing and must indicate the basis for the claim, the name and address of the creditor or his agent or attorney and the amount the claim is contingent or unliquidated, the nature of the uncertainty shall be stated. If the claim is secured, the security shall be described. The claimant shall deliver sufficient copies of the claim to the Clerk to enable the Clerk to mail one copy to the Personal Representative. All persons interested in the Estate to whom a copy of this Notice of Administration has been mailed are required, WITHIN THREE MONTHS FROM THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE, to file any objection they may have, or the qualifications of the Personal Representative, or the venue or jurisdiction of the Court.
DATED THIS 22nd day of January, 2013.
Marlin Hinrichs
22264 NW Mark Burke Rd.
Altha, FL 32421
BY: J. DAVID HOUSE, P.A.
16865 SE RIVER STREET
BLOUNTSTOWN, FL 32424
(850)674-5481
FLORIDA BAR #282359
COUNSEL FOR PERSONAL REP.
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL COURT IN AND FOR
CALHOUN COUNTY, FLORIDA
CIVIL DIVISION
CASE NO.: 072012CA000170XXXXXX
BANK OF AMERICA, N.A.
Plaintiff,
-vs-
NICKIE L. GAY A/K/A NICKIE GAY; LAMAR ANDREW GAY; UNKNOWN TENANT NO. 1; UNKNOWN TENANT NO. 2; AND ALL UNKNOWN PARTIES CLAIMING INTERESTS BY, THROUGH, UNDER OR AGAINST A NAMED DEFENDANT TO THIS ACTION, OR HAVING OR CLAIMING T HAVE ANY RIGHT, TITLE OR INTEREST IN THE PROPERTY HEREIN DESCRIBED,
Defendants.
NOTICE OF SALE
PURSUANT TO CHAPTER 45
NOTICE IS HEREBY GIVEN pursuant to an Order or Summary final Judgment of foreclosure dated January 22, 2013, and entered in Case No. 072012CA000170XXXXXX of the Circuit Court in and for Calhoun County, Florida, wherein BANK OF AMERICA, N.A., NICKIE L. GAY A/K/A NICKIE GAY; LAMAR ANDREW GAY; UNKNOWN TENANT NO. 1; UNKNOWN TENANT NO. 2; and ALL UNKNOWN PARTIES CLAIMING INTERESTS BY, THROUGH, UNDER OR AGAINST A NAMED DEFENDANT TO THIS ACTION, OR HAVING OR CLAIMING TO HAVE ANY RIGHT, TITLE OR INTEREST IN THE PROPERTY HEREIN DESCRIBED, are Defendants, I will sell to the highest and best bidder for cash at on the Front Steps of the Calhoun County Courthouse at 20859 Central Ave. E., Blountstown, FL 32424 at Calhoun County, Florida at 11:00 a.m. CST on the 2nd day of May, 2013, the following described property as set forth in said Order or Final Judgment, to-wit:
COMMENCE AT AN EXISTING CONCRETE MONUMENT MARKING THE SOUTHWEST CORNER OF SECTION 16, TOWNSHIP 2 NORTH, RANGE 9 WEST, CALHOUN COUNTY, FLORIDA AND THENCE RUN S89°34’00” E, ALONG THE SOUTH BOUNDARY LINE OF SAID SECTION 16, 1903.59 FEET TO A POINT, THENCE DEPARTING SAID SOUTH BOUNDARY LINE RUN N34°12’50” W 1268.38 FEET TO AN ELECTRICAL METAL TUBING PIPE ON THE SOUTHERLY RIGHT OF WAY LINE OF COUNTY ROAD 274, THENCE RUN N56°05’04” E ALONG SAID SOUTHERLY RIGHT OF WAY LINE, 870.0 FEET TO A CONCRETE MONUMENT ON THE EASTERLY RIGHT OF WAY LINE OF A 60 FOOT ROADWAY, UTILITIES AND DRAINAGE EASEMENT, THENCE DEPARTING SAID SOUTHERLY RIGHT OF WAY LINE RUN S34°12’59” E, ALONG THE EASTERLY RIGHT OF WAY LINE OF SAID 60 ROADWAY, UTILITIES AND DRAINAGE EASEMENT, 194.95 FEET TO A CONCRETE MONUMENT, SAID CONCRETE MONUMENT BEING ON A CURVE CONCAVE TO THE SOUTHWEST, THENCE RUN IN A SOUTHEASTERLY DIRECTION ALONG SAID EASTERLY RIGHT OF WAY LINE AND CURVE HAVING A RADIUS OF 350.00 FEET, THROUGH A CENTRAL ANGLE OF 23°12’28” FOR AN ARC LENGTH OF 142.38 FEET, CHORD OF SAID ARC BEING S22°33’45” E 141.40 FEET TO AN IRON ROD, THENCE DEPARTING SAID EASTERLY RIGHT OF WAY LINE RUN S81°17’20: E 347.23 FEET TO AN IRON ROD ON THE WESTERLY BANK OF A BRANCH, THENCE CONTINUE S81°17’20”E 10.00 FEET, MORE OR LESS, TO THE CENTER OF SAID BRANCH FOR THE POINT OF BEGINNING, THENCE FROM SAID POINT OF BEGINNING RUN N81°17’20”W 10.00 FEET MORE OR LESS, TO AN IRON ROD ON THE WESTERLY BANK OF SAID BRANCH, THENCE CONTINUE N81°17’20”W 347.23 FEET TO AN IRON ROD ON THE EASTERLY RIGHT OF WAY LINE OF SAID 60 FOOT ROADWAY, UTILITIES AND DRAINAGE EASEMENT, SAID IRON ROD BEING ON A CURVE CONCAVE TO THE SOUTHWEST, THENCE RUN IN A SOUTHERLY DIRECTION ALONG SAID EASTERLY RIGHT OF WAY LINE AND CURVE HAVING A RADIUS OF 350.00 FEET, THROUGH A CENTRAL ANGLE OF 16°22’13”FOR AN ARC LENGTH OF 100.00 FEET, CHORD OF SAID ARC BEING S02°43’24”E 99.66 FEET TO AN IRON ROD, THENCE DEPARTMENT SAID EASTERLY RIGHT OF WAY LINE RUN S75°23’05”E 370.64 FEET TO AN IRON ROD ON THE WESTERLY BANK OF SAID BRANCH, THENCE CONTINUES S75°23’05”E 10.00 FEET MORE OR LESS, TO THE CENTER OF SAID BRANCH, THENCE RUN NORTHERLY, ALONG THE CENTER OF SAID BRANCH, 147.48 FEET, MORE OR LESS, TO THE POINT OF BEGINNING.
SUBJECT TO A 15 FOOT DRAINAGE EASEMENT LYING OVER, ACROSS AND UNDER THE NORTHERLY 7.5 FEET THEREOF.
TOGETHER WITH A 60 FOOT ROADWAY, UTILITIES AND DRAINAGE EASEMENT LYING OVER, ACROSS AND UNDER THE FOLLOWING DESCRIBED PARCEL:
COMMENCE AT AN EXISTING CONCRETE MONUMENT MARKING THE SOUTHWEST CORNER OF SECTION 16, TOWNSHIP 2 NORTH, RANGE 9 WEST, CALHOUN COUNTY, FLORIDA AND THENCE RUN S89°34’00”E, ALONG THE SOUTH BOUNDARY LINE OF SAID SECTION 16, 1903.59 FEET TO A POINT; THENCE DEPARTING SAID SOUTH BOUNDARY LINE RUN N34°12’50”W 1268.38 FEET TO AN ELECTRICAL METAL TUBING PIPE ON THE SOUTHERLY RIGHT OF WAY LINE OF COUNTY ROAD 274, THENCE RUN N56°05’04”E ALONG SAID SOUTHERLY RIGHT OF WAY LINE, 810.0 FEET TO A CONCRETE MONUMENT FOR THE POINT OF BEGINNING, THENCE FROM SAID POINT OF BEGINNING CONTINUE N56°05’04”E, ALONG SAID SOUTHERLY RIGHT OF WAY LINE, 60.00 FEET TO A CONCRETE MONUMENT, THENCE DEPARTING SAID SOUTHERLY RIGHT OF WAY LINE RUN S34°12’59”E 194.95 FEET TO A CONCRETE MONUMENT, SAID CONCRETE MONUMENT BEING ON A CURVE CONCAVE TO THE SOUTHWEST, THENCE RUN IN A SOUTHERLY DIRECTION ALONG SAID CURVE HAVING A RADIUS OF 350.00 FEET, THROUGH A CENTRAL ANGLE OF 39°40’41” FOR AN ARC LENGTH OF 242.38 FEET, CHORD OF SAID ARC BEING S14°22’39”E 237.56 FEET TO AN IRON ROD, THENCE RUN N75°23’05”W 60.94 FEET TO A IRON ROD, SAID IRON ROD BEING ON A CURVE CONCAVE TO THE SOUTHWEST, THENCE RUN IN A NORTHERLY DIRECTION ALONG SAID CURVE HAVING A RADIUS OF 290.00 FEET, THROUGH A CENTRAL ANGLE OF 37°45’45” FOR AN ARC LENGTH OF 191.13 FEET, CHORD OF SAID ARC BEING N15°20’07”W 187.69 FEET TO A CONCRETE MONUMENT, THENCE RUN N34°12’59”W 195.26 FEET TO THE POINT OF BEGINNING.
TOGETHER WITH THAT CERTAIN 2008 SCOTBILT HOMES INC. MOBILE HOME; VIN#SSBHGA1100803331A AND SBHGA1100803331B; TITLE #S 100600349 AND 100600225
ANY PERSON CLAIMING AN INTEREST IN THE SURPLUS FROM THE SALE, IF ANY, OTHER THAN THE PROPERTY OWNER AS OF THE DATE OF THE LIS PENDENS MUST FILE A CLAIM WITHIN 60 DAYS AFTER THE SALE.
If you are a person with a disability who needs any accommodation in order to participate in this proceeding, you are entitled, at no cost to you, to the provision of certain assistance. Please contact the ADA Coordinator by mail at P.O. Box 1089, Panama City, FL 32402 or by phone at (850) 747-5338 at least seven (7) days before your scheduled court appearance, or immediately upon receiving this notification if the time before the scheduled appearance is less than seven (7) days. If you are hearing impaired, please call 711.
DATED at Blountstown, Florida, on January 22, 2013.
CARLA A. HAND,
As Clerk, Circuit Court
By: L. Flowers
As Deputy Clerk
Legal Notice
CITY OF BLOUNTSTOWN NOTICE
TO RECEIVE SEALED BIDS
The City of Blountstown will receive sealed bids from any qualified person, company or corporation interested in providing crape myrtles for:
CITY OF BLOUNTSTOWN 2013 ROADSIDE BEAUTIFICATION PROJECT
This project consists of delivering 150 each container grown crape myrtle plants to the City of Blountstown’s Public Works compound at 17262 NW Angle Street, Blountstown, FL 32424
Specifications can be obtained from the City of Blountstown, 20591 Central Avenue West, Blountstown, Florida 32424, (850) 674-5488. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
Bids will be received until 4:00 p.m.CST, on Tuesday, February 12, 2013 at Blountstown City Hall, 20591 Central Avenue West, Blountstown, Florida 32424, and will be opened and read publicly on Tuesday, February 12, 2013 as soon as possible after 6:00 p.m. CST at 17276 NW Angle St. All Bids shall be submitted in a sealed envelope clearly marked “Sealed Bid – CITY OF BLOUNTSTOWN 2013 ROADSIDE BEAUTIFICATION PROJECT”.
Delivery of the plants must occur within 15 calendar days from the date the Notice of Award is presented to the successful bidder.
The City of Blountstown reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of the City.
If you have any questions, please call Emory Pierce, City Manager at (850) 674 5488 or email at epierce@Blountstown.org
Legal Notice
NOTICE OF PUBLIC SALE
MALLORY TOWING & RECOVERY, INC. gives Notice of Foreclosure of Lien and intent to sell these vehicles on FEBRUARY 12, 2013, 2:00 p.m. at 18114 SR 20 W., BLOUNTSTOWN, FL 32424-4834, pursuant to subsection 713.78 of the Florida Statutes. MALLORY TOWING & RECOVERY, INC. reserves the right to accept or reject any and/or all bids.
1J4FT58L2LL252861 - 1990 JEEP
MALLORY TOWING & RECOVERY, INC.
Legal Notice
IN THE CIRCUIT COURT OF THE 14th JUDICIAL CIRCUIT
IN AND FOR
CALHOUN COUNTY, FLORIDA
CIVIL DIVISION
CASE NO. 2011-CA-000021
FCDB FF1 2008-1 Trust
Plaintiff,
-vs-
VANESSA DAWSON a/k/a Vanessa Zanovia Dawson
and all unknown parties claiming by, through, under and against the above named Defendant who are unknown to be dead or alive whether said unknown are persons, heirs, devisees, grantees, or other
claimants; UNKNOWN SPOUSE OF VANESSA DAWSON; HAYLEY MARIE VON (A MINOR CHILD THROUGH HER ATTORNEY ADLITEM; Tenant I/Unknown
Tenant; and Tenant II/Unknown Tenant,
in possession of the subject real property,
Defendants.
AMENDED NOTICE OF SALE
NOTICE IS HEREBY GIVEN pursuant to a Final Judgment/Order entered in the above noted case, that I will sell the following property situated in Calhoun County, Florida described as:
EXHIBIT “1”
Commence at the Southwest Corner of Section 34, Township 1 North, Range 8 West, in Calhoun County, Florida, thence run North 00 degrees 02 minutes East 594.00 feet, along the Section line, thence run East 75.0 feet to the Point of Beginning, thence run North 00 degrees 02 minutes East 72.0 feet to the South edge of a graded road, thence run East 75.0 feet along the South edge of said Graded Road, thence run South 00 degrees 02 minutes West 72.0 feet, thence run West 75.0 feet to the Point of Beginning.
ALSO:
Commence at the Southwest Corner of Section 34, Township 1 North, Range 8 West, In Calhoun County, Florida, thence run North 00 degrees 02 minutes East 594.0 feet, along the Section line, thence run East 150.0 feet to the Point of Beginning, thence run North 00 degrees 02 minutes East 72.0 feet to the “South right-of-way line” of a graded street, thence East 68.25 feet, along the South right-of-way line of said Graded Street, thence run South 00 degrees 02 minutes West 72.0 feet, thence run West 68.25 feet to the Point of Beginning.
ALSO:
Begin at the Southwest Corner of Section 34, Township 1 North, Range 8 West, Calhoun County, Florida and run North along the Section line 198 yards for the Point of Beginning, thence run North 72 feet, thence East 75 feet, thence South 72 feet, thence West 75 feet to the Point of Beginning. Subject to an easement on the West side for a road for City Street.
at public sale, to the highest and best bidder for cash, at Front steps at the Calhoun County Courthouse located at 20859 Central Avenue E., Blountstown, Florida, at 11:00 A.M. CST on MARCH 7, 2013. The highest bidder shall immediately post with the Clerk, a deposit equal to five percent (5%) of the final bid. The deposit must be cash or cashier check payable to the Clerk of the Court. Final payment must be made on or before 5:00 P.M. on the date of the sale by cash or cashier’s check.
ANY PERSON CLAIM AN INTEREST IN THE SURPLUS FROM THE SALE, IF ANY, OTHER THAN THE PROPERTY OWNER AS OF THE DATE OF THE LIS PENDENS MUST FILE A CLAIM WITHIN 60 DAYS AFTER THE SALE.
CARLA A. HAND
Clerk of the Court
Calhoun County, Florida
The City of Blountstown will receive sealed bids from any qualified person, company or corporation interested in constructing:
SAM ATKINS PAR
WATER TANK REPAIRS
This project consists of the removal and replacement of all the roof panels and bolts on an existing AquaStore 100,000 gallon ground storage potable water tank. The roof consists of 33 inner ring panels and 33 outer ring panels with one manway hatch and one vent. The contractor will be required to remove and replace the aerator assembly.
Plans and specifications can be obtained from the City of Blountstown, 20591 Central Avenue Wes t, Blountstown, Florida 32424, (850) 674-5488. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
Bids will be received until 4:00 p.m.CST, on Tuesday, February 12, 2013 at Blountstown City Hall, 20591 Central Avenue West, Blountstown, Florida 32424, and will be opened and read publicly on Tuesday, February 12, 2013 as soon as possible after 6:00 p.m. CST at 17276 NW Angle St. All Bids shall be submitted in a sealed envelope clearly marked “Sealed Bid – SAM ATKINS PARK WATER TANK REPAIRS”.
Completion date for this project will be 20 calendar days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $750.00 per day.
The City of Blountstown reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of the City.
If you have any questions, please call Emory Pierce, City Manager at (850) 674 5488 or email at epierce@Blountstown.org
Legal Notice
IN THE CIRCUIT COURT FOR
CALHOUN COUNTY, FLORIDA
PROBATE DIVISION
File No: 12-54PR
IN RE: ESTATE OF: SAM BAKER, JR., a/k/a
SAM BOBBY BAKER, JR.
Deceased. NOTICE OF ADMINISTRATION AND NOTICE TO CREDITORS
TO ALL PERSONS HAVING CLAIMS OR DEMANDS AGAINST THE ABOVE ESTATE AND ALL OTHER PERSONS INTERESTED IN THE ESTATE:
YOU ARE NOTIFIED that the administration of the Estate of Sam Baker, Jr., a/k/a Sam Bobby Baker, Jr., File Number 2012-54PR is pending in the Circuit Court for Calhoun County, Florida, Probate Division, 20859 Central Avenue, Blountstown, Florida 32424, the address of which is the Calhoun County Courthouse. The Personal Representative of the Estate is Tony Robinson. The name and address of the Personal Representative’s attorney is set forth below.
All persons having claims or demands against the Estate are required, WITHIN THREE MONTHS FROM THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE, to file with the Clerk of the above Court a written statement of any claim or demand they may have. Each claim must be in writing and must indicate the basis for the claim, the name and address of the creditor or his agent or attorney and the amount the claim is contingent or unliquidated, the nature of the uncertainty shall be stated. If the claim is secured, the security shall be described. The claimant shall deliver sufficient copies of the claim to the Clerk to enable the Clerk to mail one copy to the Personal Representative. All persons interested in the Estate to whom a copy of this Notice of Administration has been mailed are required, WITHIN THREE MONTHS FROM THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE, to file any objection they may have, or the qualifications of the Personal Representative, or the venue or jurisdiction of the Court.
DATED THIS 15h day January, 2013.
JAMEL BAKER
192 Delores Ln.
Midway, FL 32343
BY: J. DAVID HOUSE, P.A. J. DAVID HOUSE
16865 SE RIVER STREET
BLOUNTSTOWN, FL 32424 (850)674-5481 FLORIDA BAR #282359
COUNSEL FOR PERSONAL REP.
Legal Notice
NOTICE OF DISPOSAL
M & W SELF STORAGE RENTALS will dispose of contents of the following units on Friday, February 1, 2013 at 3:00 p.m. If not paid in full and emptied out. The unit is believed to contain household and/or personal property.
Richard Coulliette - Unit 23 South
Sheryl Taube - Unit 26 South
Josh Going - Units 35 North & 40 North
Legal Notice
IN THE CIRCUIT COURT OF THE
FOURTEENTH JUDICIAL CIRCUIT,
IN AND FOR
CALHOUN COUNTY, FLORIDA
CASE NO: 12-267CA
VANDERBILT MORTGAGE AND FINANCE, INC.
a Tennessee Corporation
P.O. Box 9800
Maryville, Tennessee 37802,
Plaintiff,
v.
MARTINE MILLS,
ANDRA D. PETERSON,
THE UNKNOWN SPOUSE OF TYRONE MILLS, and
THE UNKNOWN SPOUSE OF PURCELL SATTERWHITE
N/K/A ROBERT SATTERWHITE,
Defendants.
NOTICE OF ACTION
TO: THE UNKNOWN SPOUSE OF TYRONE MILLS:
YOU ARE NOTIFIED that a civil action has been filed against you in the Circuit Court of County of Calhoun, State of Florida, to foreclose certain real property described as follows:
SEE EXHIBIT “A”; TOGETHER WITH THAT CERTAIN 2009 CMH BLUE RIDGE MOBILE HOME, SERIAL NUMBER CLM089809TN.
Commonly known as: 27962 ST. ROSE ROAD, GRAND RIDGE, FL 32442.
You are required to file a written response with the Court and serve a copy of your written defenses, if any, to it on Timothy D. Padgett, Plaintiff’s attorney, whose address is 2878 Remington Green Circle, Tallahassee, Florida 32308, at least thirty (30) days from the date of first publication, and file the original with the clerk of this court either before service on Plaintiff’s attorney or immediately thereafter; otherwise, a default will be entered against you for the relief demanded in the complaint.
Dated this 4th day of December, 2012.
CLERK OF THE COURT
CARLA A. HAND
Legal Notice
IN THE CIRCUIT COURT OF THE 14TH JUDICIAL CIRCUIT IN AND FOR CALHOUN COUNTY, FLORIDA
CASE NO.12-318-DR
Lorenza R. Lockhart
Petitioner
and
Kenneth Lockhart
Respondent
NOTICE OF ACTION FOR
DISSOLUTION OF MARRIAGE
(No Child or Financial Support)
TO: Kenneth Lockhart
Address: Unknown
YOU ARE NOTIFIED that an action for dissolution of marriage has been filed against you and that you are required to serve a copy of your written defenses, if any, to it on Lorenza Lockhart, whose address is 11538 NW China Dawson Rd., Bristol, FL 32321 on or before February 15, 2013, and file the original with the clerk of this Court at 20859 Central Ave., E., Room 130, Blountstown, FL 32424, before service on Petitioner or immediately thereafter. If you fail to do so, a default may be entered against you for the relief demanded in the petition.
The action is asking the court to decide how the following real or personal property should be divided: NONE
Copies of all court documents in this case, including orders, are available at the Clerk of the Circuit Court’s office. You may review these documents upon request.
You must keep the Clerk of the Circuit Court’s office notified of your current address. (You may file Notice of Current Address, Florida Supreme Court Approved Family Law form 12.915.) Future papers in this lawsuit will be mailed to the address on record at the clerk’s office.
WARNING: Rule 12.285, Florida Family Law Rules of Procedures, requires certain automatic disclosure of documents and information. Failure to comply can result in sanctions, including dismissal or striking of pleadings.
Dated this January 17, 2013
Carla A. Hand
Clerk of the Circuit Court
Legal Notice
IN THE CIRCUIT COURT OF THE
FOURTEENTH JUDICIAL CIRCUIT
IN AND FOR
CALHOUN COUNTY, FLORIDA
CASE NO. 07-07-2012-CA-000048
THE BANK OF NEW YORK MELLON
FKA THE BANK OF NEW YORK,
AS TRUSTEE FOR THE CERTIFICATEHOLDERS,
CWABS, INC., ASSET-BACKED
CERTIFICATES SERIES 2007-6
Plaintiff(s),
vs.
SAMMIE STEPHENS; et al.,
Defendant
NOTICE OF SALE
PURSUANT TO CHAPTER 45
NOTICE IS HEREBY GIVEN pursuant to an Order or Final Judgment of Foreclosure dated January 18, 2013, and entered in Case No. 07-2012-CA-000048 of the Circuit Court of the 14TH Judicial Circuit in and for CALHOUN County, Florida, wherein THE BANK OF NEW YORK MELLON FKA THE BANK OF NEW YORK, AS TRUSTEE FOR THE CERTIFICATEHOLDERS, CWABS, INC. ASSET-BACKED CERTIFICATES SERIES 2007-6 is the Plaintiff and SAMMIE R. STEPHENS AND LORI A. STEPHENS are the Defendants, I will sell to the highest and best bidder for cash are held on the front steps of the Calhoun County Courthouse, 20859 Central Avenue East, Blountstown, Florida 32424, at 11:00 a.m. CST on the 25th day of April, 2013, the following described property as set forth in said Order of Final Judgment, to wit:
EAST 1/2 OF NORTHWEST 1/4 OF NORTHEAST 1/4 OF NORTHWEST 1/4, SECTION 22, TOWNSHIP 2 NORTH, RANGE 10 WEST, CALHOUN COUNTY, FLORIDA
and commonly known as 9830 INDIAN PASS RD, ALTHA, FL 32421
IF YOU ARE A PERSON CLAIMING A RIGHT TO FUNDS REMAINING AFTER THE SALE, YOU MUST FILE A CLAIM WITH THE CLERK OF COURT NO LATER THAN 60 DAYS AFTER THE SALE. IF YOU FAIL TO FILE A CLAIM, YOU WILL NOT BE ENTITLED TO ANY REMAINING FUNDS. AFTER 60 DAYS, ONLY THE OWNER OF RECORD AS OF THE DATE OF THE LIS PENDENS MAY CLAIM THE SURPLUS.
DATED at CALHOUN County, Florida, this 18th day of January, 2013.
CARLA A. HAND, Clerk
CALHOUN County, Florida
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT
IN AND FOR
CALHOUN COUNTY, FLORIDA
2011-CA-000255
Trustmark National Bank
Plaintiff,
-vs-
Rudolph L. McLeod, III a/k/a Rudolph L.
McLeod and Amy N. McLeod, Husband and
Wife; Sun Trust Bank
Defendant(s).
NOTICE OF SALE
NOTICE IS HEREBY GIVEN pursuant to an Order of Final Judgment of Foreclosure January 15, 2013, entered in Civil Case Number 2011-CA-000255 of the Circuit Court of the 14th Judicial Circuit in and for Calhoun County, Florida, wherein Trustmark National Bank, Plaintiff and Rudolph L. McLeod, III a/k/a Rudolph L. McLeod and Army N. McLeod, Husband and Wife are defendants, I, Clerk of Court, CARLA A. HAND, will sell to the highest and best bidder for cash of the FRONT STEPS OF THE CALHOUN COUNTY COURTHOUSE at 20859 CENTRAL AVE. EAST, BLOUNTSTOWN, FL 32424 at 11:00 A.M. CENTRAL STANDARD TIME on March 28, 2013, the following described property as set forth in said Final Judgment, to-wit:
COMMENCE AT THE SOUTHWEST CORNER OF NORTH HALF OF LOT 2, FRACTIONAL SECTION 12, TOWNSHIP 3 SOUTH, RANGE 10 WEST, CALHOUN COUNTY, FLORIDA, AND RUN THENCE SOUTH 89 DEGREES 54 MINUTES 25 SECONDS EAST, A DISTANCE OF 1007.00 FEET, TO THE POINT OF BEGINNING. FROM SAID POINT OF BEGINNING, THENCE RUN NORTH 00 DEGREES 05 MINUTES 35 SECONDS EAST, A DISTANCE OF 120.00 FEET, THENCE NORTH 89 DEGREES 54 MINUTES 25 SECONDS WEST, A DISTANCE OF 30.00 FEET, THENCE NORTH 00 DEGREES 05 MINUTES 35 SECONDS EAST, A DISTANCE OF 100.00 FEET, THENCE NORTH 89 DEGREES 54 MINUTES 25 SECONDS WEST, A DISTANCE OF 105.00 FEET, THENCE NORTH 00 DEGREES 05 MINUTES 35 SECONDS EAST, A DISTANCE OF 235.00 FEET, THENCE SOUTH 89 DEGREES 54 MINUTES 25 SECONDS EAST, A DISTANCE OF 305.00 FEET, TO THE WESTERLY RIGHT OF WAY BOUNDARY OF RICHARDS STREET (30 FOOT RIGHT OF WAY), THENCE SOUTH 00 DEGREES 05 MINUTES 35 SECONDS WEST, ALONG SAID WESTERLY RIGHT OF WAY BOUNDARY, A DISTANCE OF 455.00 FEET, TO THE INTERSECTION OF SAID WESTERLY RIGHT T OF WAY BOUNDARY WITH THE NORTHERLY RIGHT OF WAY BOUNDARY OF OAK GROVE ROAD, THENCE NORTH 89 DEGREES 54 MINUTES 25 SECONDS WEST, A DISTANCE OF 170.00 FEET, TO THE POINT OF BEGINNING.
ANY PERSON CLAIMING AN INTEREST IN THE SURPLUS FROM THE SALE, IF ANY, OTHER THAN THE PROPERTY OWNER AS OF THE DATE OF THE LIS PENDENS MUST FILE A CLAIM WITHIN 60 DAYS AFTER THE SALE.
CARLA A. HAND
Clerk of the Circuit Court
Legal Notice
IN THE CIRCUIT COURT OF THE
14TH JUDICIAL CIRCUIT
IN AND FOR
CALHOUN COUNTY, FLORIDA
CASE NO. 07-2009-CA-000350
PNC BANK, NATIONAL ASSOCIATION
Plaintiff,
vs.
LANA K. HATHAWAY; et al.
Defendant(s)
NOTICE OF ACTION-
FORECLOSURE PROCEEDINGS
TO: DEBORAH HATHAWAY,
including any unknown spouse of the Defendant, if remarried and if said Defendant is dead his/her respective unknown spouse, heirs, devisees, grantees, assignees, creditors, lien holders, and trustees, and all other persons claiming by, through, under or against the named Defendant; and the aforementioned named Defendant and such of the aforementioned unknown Defendant and such of the unknown named Defendant as may be infants, incompetents, or otherwise not sui juris.
YOU ARE HEREBY NOTIFIED that an action to foreclose a mortgage on the following described property, to-wit:
Begin at the Northeast corner of the East Quarter of the Southwest Quarter of the Northeast Quarter of Section 30, township 2 North, Range 11 West of Calhoun County, Florida; thence run South 00°04’10” East, along the East line of the East Quarter of the Southwest Quarter of the Northeast Quarter, 1,325.39 feet; thence departing said East line on a bearing of South 89°56’23” West, 664.12 feet; thence north 00°04’10” West, 620.89 feet to a point on the centerline of Chammbry Road; thence South 85°53’09” East, along said centerline, 30.70 feet to a point and call this point “A”; thence meander Easterly and Northerly along said centerline so as to reach a point being North 56°36’13” East and 48.03 feet from aforesaid point “A”; thence run North 04°30’03” West, along aforesaid centerline, 680.18 feet; thence departing said centerline on a bearing of North 89°56’23” East 643.84 feet to the point of beginning Subject to East 30 feet for right of way of Chammbry Road.
ACCESS HAS NOT BEEN DETERMINED - POSSIBILITY OF NO ACCESS
More commonly known as 24219 NW Chammbry Ln, Fountain, FL 32438
This action has been filed against you, and you are required to serve a copy of your written defense, if any, to it on Plaintiff’s attorney, Weltman, Weinberg & Reis, Co., L.P.A., whose address is 550 West Cypress Creek Road, Suite 550, Fort Lauderdale, FL 33309, on or before 30 days after date of first publication, January 23, 2013, and file the original with the Clerk of the Circuit Court either before service on Plaintiff’s attorney or immediately thereafter; otherwise a default will be entered against you for the relief demanded in the Complaint.
Witness my hand and seal of this Court on the 18th day of January, 2013.
Carla A. Hand
Clerk of Circuit Court
Legal Notice
BID NOTICE
STATE HOUSING INITIATIVES
“SHIP PROGRAM”
The Calhoun Board of County Commissioners will accept sealed bids on behalf of its State Housing Initiatives Partnership “SHIP” Program for the rehabilitation on houses until 12:00 p.m. local time on Tuesday, February 19, 2012. Bids may be delivered to the Clerk’s Office in the Calhoun County Courthouse, Blountstown, Florida 32424. Bids must arrive before deadline. Bids will be opened at 5:00 p.m. or as soon afterwards as possible. Bids must be sealed in an envelope marked “sealed bid for ship rehab” and identified by the name of the firm, and the date and time of the bid opening.
A mandatory pre-bid conference will be held on Tuesday, February 12, 2012, at 9:00 a.m. local time in room 117 in the Calhoun County Building Department located on the 1st floor of the Calhoun County Courthouse. Bid sheets and specifications will be available at the meeting. It is the responsibility of the contractor to purchase all permits deemed necessary. Bidders must provide proof of general liability and workman’s compensation insurance in the bid package. The insurance must be in force at the time of the bid opening. As an alternative to providing workman’s compensation insurance, the prospective bidder shall provide proof of worker’s compensation exemption. Any person claiming to be exempt shall be subject to an on-the-job inspection for proof of exemption and license of all workers on job site.
Minority contractors are encouraged to participate. Calhoun County is an equal opportunity jurisdiction. The Calhoun County Board of County Commissioners reserves the right to reject any and all bids and to waive any informality. The signing of the contract is contingent upon the approval of and/or release of funds by the Florida housing finance agency.
CALHOUN COUNTY IS /AN EQUAL OPPORTUNITY/FAIR HOUSING COUNTY.
Legal Notice
ACCEPTING SEALED BIDS
THE BOARD OF COUNTY COMMISSIONERS OF CALHOUN COUNTY WILL BE ACCEPTING SEALED BIDS FOR RESIDENTIAL SEPTIC SYSTEMS ON TUESDAY, February 19, 2013. BIDS MUST BE TURNED IN TO THE CALHOUN COUNTY CLERK’S OFFICE BY 12:00 P.M. AND WILL BE OPENED AT 5:00 P.M. OR AS SOON THEREAFTER AS IS PRACTICAL.
SPECIFICATIONS MAY BE PICKED UP IN THE “SHIP” OFFICE. FOR MORE INFORMATION YOU MAY CALL DAN CLEMONS AT 674-2571 or 674-4551
THE BOARD RESERVES THE RIGHT TO ACCEPT OR REJECT ANY OR ALL BIDS.
CALHOUN COUNTY IS /AN EQUAL OPPORTUNITY/FAIR HOUSING COUNTY
Legal Notice
IN THE CIRCUIT COURT FOR
CALHOUN COUNTY, FLORIDA
PROBATE DIVISION
File No: 13-02PR
IN RE: ESTATE OF:
RHONDA FAYE HINRICHS,
Deceased.
NOTICE OF ADMINISTRATION AND
NOTICE TO CREDITORS
TO ALL PERSONS HAVING CLAIMS OR DEMANDS AGAINST THE ABOVE ESTATE AND ALL OTHER PERSONS INTERESTED IN THE ESTATE:
YOU ARE NOTIFIED that the administration of the Estate of Rhonda Faye Hinrichs, File Number 2013-02PR is pending in the Circuit Court for Calhoun County, Florida, Probate Division, 20859 Central Avenue, Blountstown, Florida 32424, the address of which is the Calhoun County Courthouse. The Personal Representative of the Estate is Marlin Hinrichs. The name and address of the Personal Representative’s attorney is set forth below.
All persons having claims or demands against the Estate are required, WITHIN THREE MONTHS FROM THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE, to file with the Clerk of the above Court a written statement of any claim or demand they may have. Each claim must be in writing and must indicate the basis for the claim, the name and address of the creditor or his agent or attorney and the amount the claim is contingent or unliquidated, the nature of the uncertainty shall be stated. If the claim is secured, the security shall be described. The claimant shall deliver sufficient copies of the claim to the Clerk to enable the Clerk to mail one copy to the Personal Representative. All persons interested in the Estate to whom a copy of this Notice of Administration has been mailed are required, WITHIN THREE MONTHS FROM THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE, to file any objection they may have, or the qualifications of the Personal Representative, or the venue or jurisdiction of the Court.
DATED THIS 22nd day of January, 2013.
Marlin Hinrichs
22264 NW Mark Burke Rd.
Altha, FL 32421
BY: J. DAVID HOUSE, P.A.
16865 SE RIVER STREET
BLOUNTSTOWN, FL 32424
(850)674-5481
FLORIDA BAR #282359
COUNSEL FOR PERSONAL REP.
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL COURT IN AND FOR
CALHOUN COUNTY, FLORIDA
CIVIL DIVISION
CASE NO.: 072012CA000170XXXXXX
BANK OF AMERICA, N.A.
Plaintiff,
-vs-
NICKIE L. GAY A/K/A NICKIE GAY; LAMAR ANDREW GAY; UNKNOWN TENANT NO. 1; UNKNOWN TENANT NO. 2; AND ALL UNKNOWN PARTIES CLAIMING INTERESTS BY, THROUGH, UNDER OR AGAINST A NAMED DEFENDANT TO THIS ACTION, OR HAVING OR CLAIMING T HAVE ANY RIGHT, TITLE OR INTEREST IN THE PROPERTY HEREIN DESCRIBED,
Defendants.
NOTICE OF SALE
PURSUANT TO CHAPTER 45
NOTICE IS HEREBY GIVEN pursuant to an Order or Summary final Judgment of foreclosure dated January 22, 2013, and entered in Case No. 072012CA000170XXXXXX of the Circuit Court in and for Calhoun County, Florida, wherein BANK OF AMERICA, N.A., NICKIE L. GAY A/K/A NICKIE GAY; LAMAR ANDREW GAY; UNKNOWN TENANT NO. 1; UNKNOWN TENANT NO. 2; and ALL UNKNOWN PARTIES CLAIMING INTERESTS BY, THROUGH, UNDER OR AGAINST A NAMED DEFENDANT TO THIS ACTION, OR HAVING OR CLAIMING TO HAVE ANY RIGHT, TITLE OR INTEREST IN THE PROPERTY HEREIN DESCRIBED, are Defendants, I will sell to the highest and best bidder for cash at on the Front Steps of the Calhoun County Courthouse at 20859 Central Ave. E., Blountstown, FL 32424 at Calhoun County, Florida at 11:00 a.m. CST on the 2nd day of May, 2013, the following described property as set forth in said Order or Final Judgment, to-wit:
COMMENCE AT AN EXISTING CONCRETE MONUMENT MARKING THE SOUTHWEST CORNER OF SECTION 16, TOWNSHIP 2 NORTH, RANGE 9 WEST, CALHOUN COUNTY, FLORIDA AND THENCE RUN S89°34’00” E, ALONG THE SOUTH BOUNDARY LINE OF SAID SECTION 16, 1903.59 FEET TO A POINT, THENCE DEPARTING SAID SOUTH BOUNDARY LINE RUN N34°12’50” W 1268.38 FEET TO AN ELECTRICAL METAL TUBING PIPE ON THE SOUTHERLY RIGHT OF WAY LINE OF COUNTY ROAD 274, THENCE RUN N56°05’04” E ALONG SAID SOUTHERLY RIGHT OF WAY LINE, 870.0 FEET TO A CONCRETE MONUMENT ON THE EASTERLY RIGHT OF WAY LINE OF A 60 FOOT ROADWAY, UTILITIES AND DRAINAGE EASEMENT, THENCE DEPARTING SAID SOUTHERLY RIGHT OF WAY LINE RUN S34°12’59” E, ALONG THE EASTERLY RIGHT OF WAY LINE OF SAID 60 ROADWAY, UTILITIES AND DRAINAGE EASEMENT, 194.95 FEET TO A CONCRETE MONUMENT, SAID CONCRETE MONUMENT BEING ON A CURVE CONCAVE TO THE SOUTHWEST, THENCE RUN IN A SOUTHEASTERLY DIRECTION ALONG SAID EASTERLY RIGHT OF WAY LINE AND CURVE HAVING A RADIUS OF 350.00 FEET, THROUGH A CENTRAL ANGLE OF 23°12’28” FOR AN ARC LENGTH OF 142.38 FEET, CHORD OF SAID ARC BEING S22°33’45” E 141.40 FEET TO AN IRON ROD, THENCE DEPARTING SAID EASTERLY RIGHT OF WAY LINE RUN S81°17’20: E 347.23 FEET TO AN IRON ROD ON THE WESTERLY BANK OF A BRANCH, THENCE CONTINUE S81°17’20”E 10.00 FEET, MORE OR LESS, TO THE CENTER OF SAID BRANCH FOR THE POINT OF BEGINNING, THENCE FROM SAID POINT OF BEGINNING RUN N81°17’20”W 10.00 FEET MORE OR LESS, TO AN IRON ROD ON THE WESTERLY BANK OF SAID BRANCH, THENCE CONTINUE N81°17’20”W 347.23 FEET TO AN IRON ROD ON THE EASTERLY RIGHT OF WAY LINE OF SAID 60 FOOT ROADWAY, UTILITIES AND DRAINAGE EASEMENT, SAID IRON ROD BEING ON A CURVE CONCAVE TO THE SOUTHWEST, THENCE RUN IN A SOUTHERLY DIRECTION ALONG SAID EASTERLY RIGHT OF WAY LINE AND CURVE HAVING A RADIUS OF 350.00 FEET, THROUGH A CENTRAL ANGLE OF 16°22’13”FOR AN ARC LENGTH OF 100.00 FEET, CHORD OF SAID ARC BEING S02°43’24”E 99.66 FEET TO AN IRON ROD, THENCE DEPARTMENT SAID EASTERLY RIGHT OF WAY LINE RUN S75°23’05”E 370.64 FEET TO AN IRON ROD ON THE WESTERLY BANK OF SAID BRANCH, THENCE CONTINUES S75°23’05”E 10.00 FEET MORE OR LESS, TO THE CENTER OF SAID BRANCH, THENCE RUN NORTHERLY, ALONG THE CENTER OF SAID BRANCH, 147.48 FEET, MORE OR LESS, TO THE POINT OF BEGINNING.
SUBJECT TO A 15 FOOT DRAINAGE EASEMENT LYING OVER, ACROSS AND UNDER THE NORTHERLY 7.5 FEET THEREOF.
TOGETHER WITH A 60 FOOT ROADWAY, UTILITIES AND DRAINAGE EASEMENT LYING OVER, ACROSS AND UNDER THE FOLLOWING DESCRIBED PARCEL:
COMMENCE AT AN EXISTING CONCRETE MONUMENT MARKING THE SOUTHWEST CORNER OF SECTION 16, TOWNSHIP 2 NORTH, RANGE 9 WEST, CALHOUN COUNTY, FLORIDA AND THENCE RUN S89°34’00”E, ALONG THE SOUTH BOUNDARY LINE OF SAID SECTION 16, 1903.59 FEET TO A POINT; THENCE DEPARTING SAID SOUTH BOUNDARY LINE RUN N34°12’50”W 1268.38 FEET TO AN ELECTRICAL METAL TUBING PIPE ON THE SOUTHERLY RIGHT OF WAY LINE OF COUNTY ROAD 274, THENCE RUN N56°05’04”E ALONG SAID SOUTHERLY RIGHT OF WAY LINE, 810.0 FEET TO A CONCRETE MONUMENT FOR THE POINT OF BEGINNING, THENCE FROM SAID POINT OF BEGINNING CONTINUE N56°05’04”E, ALONG SAID SOUTHERLY RIGHT OF WAY LINE, 60.00 FEET TO A CONCRETE MONUMENT, THENCE DEPARTING SAID SOUTHERLY RIGHT OF WAY LINE RUN S34°12’59”E 194.95 FEET TO A CONCRETE MONUMENT, SAID CONCRETE MONUMENT BEING ON A CURVE CONCAVE TO THE SOUTHWEST, THENCE RUN IN A SOUTHERLY DIRECTION ALONG SAID CURVE HAVING A RADIUS OF 350.00 FEET, THROUGH A CENTRAL ANGLE OF 39°40’41” FOR AN ARC LENGTH OF 242.38 FEET, CHORD OF SAID ARC BEING S14°22’39”E 237.56 FEET TO AN IRON ROD, THENCE RUN N75°23’05”W 60.94 FEET TO A IRON ROD, SAID IRON ROD BEING ON A CURVE CONCAVE TO THE SOUTHWEST, THENCE RUN IN A NORTHERLY DIRECTION ALONG SAID CURVE HAVING A RADIUS OF 290.00 FEET, THROUGH A CENTRAL ANGLE OF 37°45’45” FOR AN ARC LENGTH OF 191.13 FEET, CHORD OF SAID ARC BEING N15°20’07”W 187.69 FEET TO A CONCRETE MONUMENT, THENCE RUN N34°12’59”W 195.26 FEET TO THE POINT OF BEGINNING.
TOGETHER WITH THAT CERTAIN 2008 SCOTBILT HOMES INC. MOBILE HOME; VIN#SSBHGA1100803331A AND SBHGA1100803331B; TITLE #S 100600349 AND 100600225
ANY PERSON CLAIMING AN INTEREST IN THE SURPLUS FROM THE SALE, IF ANY, OTHER THAN THE PROPERTY OWNER AS OF THE DATE OF THE LIS PENDENS MUST FILE A CLAIM WITHIN 60 DAYS AFTER THE SALE.
If you are a person with a disability who needs any accommodation in order to participate in this proceeding, you are entitled, at no cost to you, to the provision of certain assistance. Please contact the ADA Coordinator by mail at P.O. Box 1089, Panama City, FL 32402 or by phone at (850) 747-5338 at least seven (7) days before your scheduled court appearance, or immediately upon receiving this notification if the time before the scheduled appearance is less than seven (7) days. If you are hearing impaired, please call 711.
DATED at Blountstown, Florida, on January 22, 2013.
CARLA A. HAND,
As Clerk, Circuit Court
By: L. Flowers
As Deputy Clerk
Legal Notice
CITY OF BLOUNTSTOWN NOTICE
TO RECEIVE SEALED BIDS
The City of Blountstown will receive sealed bids from any qualified person, company or corporation interested in providing crape myrtles for:
CITY OF BLOUNTSTOWN 2013 ROADSIDE BEAUTIFICATION PROJECT
This project consists of delivering 150 each container grown crape myrtle plants to the City of Blountstown’s Public Works compound at 17262 NW Angle Street, Blountstown, FL 32424
Specifications can be obtained from the City of Blountstown, 20591 Central Avenue West, Blountstown, Florida 32424, (850) 674-5488. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
Bids will be received until 4:00 p.m.CST, on Tuesday, February 12, 2013 at Blountstown City Hall, 20591 Central Avenue West, Blountstown, Florida 32424, and will be opened and read publicly on Tuesday, February 12, 2013 as soon as possible after 6:00 p.m. CST at 17276 NW Angle St. All Bids shall be submitted in a sealed envelope clearly marked “Sealed Bid – CITY OF BLOUNTSTOWN 2013 ROADSIDE BEAUTIFICATION PROJECT”.
Delivery of the plants must occur within 15 calendar days from the date the Notice of Award is presented to the successful bidder.
The City of Blountstown reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of the City.
If you have any questions, please call Emory Pierce, City Manager at (850) 674 5488 or email at epierce@Blountstown.org
Legal Notice
NOTICE OF PUBLIC SALE
MALLORY TOWING & RECOVERY, INC. gives Notice of Foreclosure of Lien and intent to sell these vehicles on FEBRUARY 12, 2013, 2:00 p.m. at 18114 SR 20 W., BLOUNTSTOWN, FL 32424-4834, pursuant to subsection 713.78 of the Florida Statutes. MALLORY TOWING & RECOVERY, INC. reserves the right to accept or reject any and/or all bids.
1J4FT58L2LL252861 - 1990 JEEP
MALLORY TOWING & RECOVERY, INC.
Legal Notice
IN THE CIRCUIT COURT OF THE 14th JUDICIAL CIRCUIT
IN AND FOR
CALHOUN COUNTY, FLORIDA
CIVIL DIVISION
CASE NO. 2011-CA-000021
FCDB FF1 2008-1 Trust
Plaintiff,
-vs-
VANESSA DAWSON a/k/a Vanessa Zanovia Dawson
and all unknown parties claiming by, through, under and against the above named Defendant who are unknown to be dead or alive whether said unknown are persons, heirs, devisees, grantees, or other
claimants; UNKNOWN SPOUSE OF VANESSA DAWSON; HAYLEY MARIE VON (A MINOR CHILD THROUGH HER ATTORNEY ADLITEM; Tenant I/Unknown
Tenant; and Tenant II/Unknown Tenant,
in possession of the subject real property,
Defendants.
AMENDED NOTICE OF SALE
NOTICE IS HEREBY GIVEN pursuant to a Final Judgment/Order entered in the above noted case, that I will sell the following property situated in Calhoun County, Florida described as:
EXHIBIT “1”
Commence at the Southwest Corner of Section 34, Township 1 North, Range 8 West, in Calhoun County, Florida, thence run North 00 degrees 02 minutes East 594.00 feet, along the Section line, thence run East 75.0 feet to the Point of Beginning, thence run North 00 degrees 02 minutes East 72.0 feet to the South edge of a graded road, thence run East 75.0 feet along the South edge of said Graded Road, thence run South 00 degrees 02 minutes West 72.0 feet, thence run West 75.0 feet to the Point of Beginning.
ALSO:
Commence at the Southwest Corner of Section 34, Township 1 North, Range 8 West, In Calhoun County, Florida, thence run North 00 degrees 02 minutes East 594.0 feet, along the Section line, thence run East 150.0 feet to the Point of Beginning, thence run North 00 degrees 02 minutes East 72.0 feet to the “South right-of-way line” of a graded street, thence East 68.25 feet, along the South right-of-way line of said Graded Street, thence run South 00 degrees 02 minutes West 72.0 feet, thence run West 68.25 feet to the Point of Beginning.
ALSO:
Begin at the Southwest Corner of Section 34, Township 1 North, Range 8 West, Calhoun County, Florida and run North along the Section line 198 yards for the Point of Beginning, thence run North 72 feet, thence East 75 feet, thence South 72 feet, thence West 75 feet to the Point of Beginning. Subject to an easement on the West side for a road for City Street.
at public sale, to the highest and best bidder for cash, at Front steps at the Calhoun County Courthouse located at 20859 Central Avenue E., Blountstown, Florida, at 11:00 A.M. CST on MARCH 7, 2013. The highest bidder shall immediately post with the Clerk, a deposit equal to five percent (5%) of the final bid. The deposit must be cash or cashier check payable to the Clerk of the Court. Final payment must be made on or before 5:00 P.M. on the date of the sale by cash or cashier’s check.
ANY PERSON CLAIM AN INTEREST IN THE SURPLUS FROM THE SALE, IF ANY, OTHER THAN THE PROPERTY OWNER AS OF THE DATE OF THE LIS PENDENS MUST FILE A CLAIM WITHIN 60 DAYS AFTER THE SALE.
CARLA A. HAND
Clerk of the Court
Calhoun County, Florida
Trackbacks
Trackback specific URI for this entry
No Trackbacks