Legals for 06-30-11
Legal Notice
INVITATION TO BID
The Calhoun County School Board will receive sealed bids until 3:00 PM, CT, Thursday, July 14, 2011, for the purchase of the following:
Bread Products (hamburger buns, wiener buns, sub buns and sandwich loafs) for use in the school cafeterias for the bid period of July 18, 2011 - June 30, 2012.
Any additional information or bid forms required may be obtained at the Office of the Superintendent, 20859 Central Avenue East, RM-G20, Blountstown, Florida 32424. Each bidder submitting a bid must use bid forms, otherwise bids will not be considered.
Any bid submitted after the specified hour and date will not be opened or considered. The Board accepts no responsibility for mailed proposals that arrive at the Superintendent’s Office after the above stated time even though the envelope may reflect a postmark prior to the above stated date.
The Board reserves the right to accept or reject any or all bids. The decision of the Board will be final. No bid may be withdrawn by any bidder for a period of thirty (30) days after bids are opened.
Timothy Smith, Chairman
Calhoun County School Board
ATTEST:
Wilson T. McClellan, Superintendent
Calhoun County Schools
BOARD MEETS SECOND THURSDAY
OF EACH MONTH
PHONE 674-5927
CALHOUN COUNTY SCHOOL BOARD
WILSON T. MCCLELLAN, Superintendent
20859 Central Ave E, RM-G20
BLOUNTSTOWN, FLORIDA 32424
“An Equal Opportunity Employer”
Legal Notice
RUTH W. ATTAWAY
CLERK OF CIRCUIT COURT
20859 CENTRAL AVENUE, EAST
BLOUNTSTOWN, FLORIDA 32424
NOTICE OF APPLICATION
FOR TAX DEED
NOTICE IS HEREBY GIVEN THAT Morgan & Cora Tucker is the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number and year of issuance, the description of the property, and the names in which it was assessed are as follows;
CERTIFICATE NO.714,
YEAR OF ISSUANCE 2009
DESCRIPTION OF PROPERTY
Parcel # 25-2N- 11-0000-0010-0102
Commence at the SE Corner of the SW ? of the NW ? of the SE ? of Section 25, Township 2 North, Range 11 West, for the POINT OF BEGINNING; thence West 400 feet; thence North 175 feet ; thence East 130 feet; thence South 110 feet; thence East to the East boundary of the SW ? of the SE 1/4; thence South to 65 feet, more or less to the POINT OF BEGINNING.
NAME IN WHICH ASSESSED
Charles Justus
23584 NW Armadillo Lane
Altha, Fl 32421
Said property being in the County of CALHOUN, STATE OF FLORIDA. Unless such certificate shall be redeemed according to law, the property described in such certificate shall be SOLD to the highest bidder at the Courthouse door on
August 4, 2011 At 10:00 A.M. CST.
By; Robie Bennett
Deputy ClerkRUTH W. ATTAWAY
Clerk of Circuit Court of
Calhoun County, Florida
Legal Notice
NOTICE OF ADOPTION
OF RESOLUTION
NOTICE IS HEREBY GIVEN that the Board of County Commissioners in and for Calhoun County, Florida, after public hearing, conducted after due public notice, has adopted a Resolution abandoning, vacating, discontinuing and closing for use as a public street, road, or other place for travel, that portion of the Musgrove Road in Calhoun County, more particularly described as:
That portion of Musgrove Road lying between Bodiford-Oglesby
Road and Buddy Johnson Road.
This Resolution further provides that the right, title and/or interest of Calhoun County, and the public, heretofore acquired by Calhoun County, is renounced and disclaimed.
WITNESS my hand and official seal, this the 21st day of June, 2011.
BOARD OF COUNTY COMMISSIONERS
CALHOUN COUNTY, FLORIDA
BY: /s/ Harold Pickron Chairman
Legal Notice
CHARLIE JOHNS STREET SIDEWALK PROJECT # 013.066
NOTICE TO RECEIVE SEALED BIDS
The City of Blountstown will receive sealed bids from any qualified person, company or corporation interested in constructing:
CHARLIE JOHNS STREET SIDEWALK
This project consists of concrete sidewalk construction, pedestrian bridge and minor drainage improvements along Charlie Johns Street, Burns, Crozier, and Finlay Streets.
All bidders shall be pre-qualified with the Florida Department of Transportation per Section 2-1 of the F.D.O.T. Standard Specifications for Road and Bridge Construction, 2010 edition.
Plans and specifications can be obtained at Preble-Rish, Inc., 20684 Central Avenue East, Blountstown, Florida 32424, (850)674-3300. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
Bids will be received until 12:00 NOON CST, on Tuesday, July 19, 2011 at Blountstown City Hall, 20591 Central Avenue West, Blountstown, Florida 32424, and will be opened and read publicly on Tuesday, July 19, 2011 at 5:00 p.m. CST at the City Council Meeting Room at 17262 NW Angle St., Blountstown, FL 32424. All Bids shall be submitted in an envelope clearly marked “Sealed Bid – CHARLIE JOHNS STREET SIDEWALK”.
Completion date for these projects will be 120 days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $750.00 per day.
Please indicate on the envelope your company name, that this is a sealed bid, and the bid number.
The original bid plus two (2) copies should be included.
Cost for Plans and Specifications will be $100.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC.
The City of Blountstown reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of the City.
If you have any questions, please call Justin Ford at (850) 674-3300 or email at HYPERLINK “mailto:fordj@preble-rish.com” fordj@preble-rish.com.
Legal Notice
INVITATION TO BID ON RECYCLABLE ITEMS
Notice is hereby given that sealed bid proposals for recyclable warehoused items to be SOLD will be received by the Board of Commissioners of Calhoun County, Florida until 12:00 P.M. (CT), on Wednesday, July 6, 2011, for and on behalf of Calhoun County, Florida. Bids will be publicly opened and read aloud at 2:00 P.M. (CT), on Wednesday, July 6, 2011, or as soon thereafter as practical on that date.
395 BALES OF CARDBOARD
40 BALES OF NEWSPAPER
7 BALES OF STEEL CANS
9 BALES OF ALUMINUM CANS
12 BALES OF #1 PLASTIC
8 BALES OF #2 PLASTIC
Bidders must show in their bid the total price per ton F.O.B., Calhoun County Recycling Center, Blountstown, Florida. Bidders may bid on one or ALL items. All quantities are approximate.
Please indicate on the envelope that this is a sealed bid, the bidders name, address and what the bid is for: “Bid on Baled Cardboard, Newspaper, Steel Cans, Aluminum Cans #1 Plastic and/or #2 Plastic.”
Failure to make payment within thirty (30) days of invoice will result in 1.5% penalty, compounded monthly. If payment is not received within sixty (60) days of invoice, bidder could be prohibited from future purchases.
Address all bids to the Board of County Commissioners, Calhoun County Courthouse, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424.
The Board reserves the right to waive informalities in any bid, to accept and/or reject any or all bids in whole or in part with just cause, and to accept the bid that in their judgment will be in the best interest of Calhoun County.
If you have any questions, please call Don A. “Sonny” O’Bryan at (850) 674-8075.
The Calhoun County School Board will receive sealed bids until 3:00 PM, CT, Thursday, July 14, 2011, for the purchase of the following:
Bread Products (hamburger buns, wiener buns, sub buns and sandwich loafs) for use in the school cafeterias for the bid period of July 18, 2011 - June 30, 2012.
Any additional information or bid forms required may be obtained at the Office of the Superintendent, 20859 Central Avenue East, RM-G20, Blountstown, Florida 32424. Each bidder submitting a bid must use bid forms, otherwise bids will not be considered.
Any bid submitted after the specified hour and date will not be opened or considered. The Board accepts no responsibility for mailed proposals that arrive at the Superintendent’s Office after the above stated time even though the envelope may reflect a postmark prior to the above stated date.
The Board reserves the right to accept or reject any or all bids. The decision of the Board will be final. No bid may be withdrawn by any bidder for a period of thirty (30) days after bids are opened.
Timothy Smith, Chairman
Calhoun County School Board
ATTEST:
Wilson T. McClellan, Superintendent
Calhoun County Schools
BOARD MEETS SECOND THURSDAY
OF EACH MONTH
PHONE 674-5927
CALHOUN COUNTY SCHOOL BOARD
WILSON T. MCCLELLAN, Superintendent
20859 Central Ave E, RM-G20
BLOUNTSTOWN, FLORIDA 32424
“An Equal Opportunity Employer”
Legal Notice
RUTH W. ATTAWAY
CLERK OF CIRCUIT COURT
20859 CENTRAL AVENUE, EAST
BLOUNTSTOWN, FLORIDA 32424
NOTICE OF APPLICATION
FOR TAX DEED
NOTICE IS HEREBY GIVEN THAT Morgan & Cora Tucker is the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number and year of issuance, the description of the property, and the names in which it was assessed are as follows;
CERTIFICATE NO.714,
YEAR OF ISSUANCE 2009
DESCRIPTION OF PROPERTY
Parcel # 25-2N- 11-0000-0010-0102
Commence at the SE Corner of the SW ? of the NW ? of the SE ? of Section 25, Township 2 North, Range 11 West, for the POINT OF BEGINNING; thence West 400 feet; thence North 175 feet ; thence East 130 feet; thence South 110 feet; thence East to the East boundary of the SW ? of the SE 1/4; thence South to 65 feet, more or less to the POINT OF BEGINNING.
NAME IN WHICH ASSESSED
Charles Justus
23584 NW Armadillo Lane
Altha, Fl 32421
Said property being in the County of CALHOUN, STATE OF FLORIDA. Unless such certificate shall be redeemed according to law, the property described in such certificate shall be SOLD to the highest bidder at the Courthouse door on
August 4, 2011 At 10:00 A.M. CST.
By; Robie Bennett
Deputy ClerkRUTH W. ATTAWAY
Clerk of Circuit Court of
Calhoun County, Florida
Legal Notice
NOTICE OF ADOPTION
OF RESOLUTION
NOTICE IS HEREBY GIVEN that the Board of County Commissioners in and for Calhoun County, Florida, after public hearing, conducted after due public notice, has adopted a Resolution abandoning, vacating, discontinuing and closing for use as a public street, road, or other place for travel, that portion of the Musgrove Road in Calhoun County, more particularly described as:
That portion of Musgrove Road lying between Bodiford-Oglesby
Road and Buddy Johnson Road.
This Resolution further provides that the right, title and/or interest of Calhoun County, and the public, heretofore acquired by Calhoun County, is renounced and disclaimed.
WITNESS my hand and official seal, this the 21st day of June, 2011.
BOARD OF COUNTY COMMISSIONERS
CALHOUN COUNTY, FLORIDA
BY: /s/ Harold Pickron Chairman
Legal Notice
CHARLIE JOHNS STREET SIDEWALK PROJECT # 013.066
NOTICE TO RECEIVE SEALED BIDS
The City of Blountstown will receive sealed bids from any qualified person, company or corporation interested in constructing:
CHARLIE JOHNS STREET SIDEWALK
This project consists of concrete sidewalk construction, pedestrian bridge and minor drainage improvements along Charlie Johns Street, Burns, Crozier, and Finlay Streets.
All bidders shall be pre-qualified with the Florida Department of Transportation per Section 2-1 of the F.D.O.T. Standard Specifications for Road and Bridge Construction, 2010 edition.
Plans and specifications can be obtained at Preble-Rish, Inc., 20684 Central Avenue East, Blountstown, Florida 32424, (850)674-3300. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
Bids will be received until 12:00 NOON CST, on Tuesday, July 19, 2011 at Blountstown City Hall, 20591 Central Avenue West, Blountstown, Florida 32424, and will be opened and read publicly on Tuesday, July 19, 2011 at 5:00 p.m. CST at the City Council Meeting Room at 17262 NW Angle St., Blountstown, FL 32424. All Bids shall be submitted in an envelope clearly marked “Sealed Bid – CHARLIE JOHNS STREET SIDEWALK”.
Completion date for these projects will be 120 days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $750.00 per day.
Please indicate on the envelope your company name, that this is a sealed bid, and the bid number.
The original bid plus two (2) copies should be included.
Cost for Plans and Specifications will be $100.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC.
The City of Blountstown reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of the City.
If you have any questions, please call Justin Ford at (850) 674-3300 or email at HYPERLINK “mailto:fordj@preble-rish.com” fordj@preble-rish.com.
Legal Notice
INVITATION TO BID ON RECYCLABLE ITEMS
Notice is hereby given that sealed bid proposals for recyclable warehoused items to be SOLD will be received by the Board of Commissioners of Calhoun County, Florida until 12:00 P.M. (CT), on Wednesday, July 6, 2011, for and on behalf of Calhoun County, Florida. Bids will be publicly opened and read aloud at 2:00 P.M. (CT), on Wednesday, July 6, 2011, or as soon thereafter as practical on that date.
395 BALES OF CARDBOARD
40 BALES OF NEWSPAPER
7 BALES OF STEEL CANS
9 BALES OF ALUMINUM CANS
12 BALES OF #1 PLASTIC
8 BALES OF #2 PLASTIC
Bidders must show in their bid the total price per ton F.O.B., Calhoun County Recycling Center, Blountstown, Florida. Bidders may bid on one or ALL items. All quantities are approximate.
Please indicate on the envelope that this is a sealed bid, the bidders name, address and what the bid is for: “Bid on Baled Cardboard, Newspaper, Steel Cans, Aluminum Cans #1 Plastic and/or #2 Plastic.”
Failure to make payment within thirty (30) days of invoice will result in 1.5% penalty, compounded monthly. If payment is not received within sixty (60) days of invoice, bidder could be prohibited from future purchases.
Address all bids to the Board of County Commissioners, Calhoun County Courthouse, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424.
The Board reserves the right to waive informalities in any bid, to accept and/or reject any or all bids in whole or in part with just cause, and to accept the bid that in their judgment will be in the best interest of Calhoun County.
If you have any questions, please call Don A. “Sonny” O’Bryan at (850) 674-8075.
Trackbacks
Trackback specific URI for this entry
No Trackbacks