Legal Notices For 08-05-09
Legal Notices For 08-05-09
Legal Notice
The Calhoun County School Board proposes to introduce and amend policies for Calhoun County Schools as follows:
ADMINISTRATIVE PROCEDURES ACT
CALHOUN COUNTY SCHOOLS
CHAPTER 5-STUDENTS
CHAPTER 6-HUMAN RESOURCES
Introducing and Amending Policy:
Policy 5.14 Homeless Students
Policy 5.64 Nutrition, Physical Fitness, and Wellness
Policy 6.531 DROP
Policy 6.81 Social Security Number Collection and Usage
Policy 6.912 Terminal Sick Leave and Vacation Pay
The entire proposals are available for viewing at the School Superintendent’s Office, Room G-20, Calhoun County Court House, Blountstown, Florida.
A hearing will be held on the above policies in the Courthouse in Blountstown, Florida at the Regular School Board meeting on Tuesday, August 11, 2009 at 5:00 p.m.
Kelly King, Chairperson
Calhoun County School Board
Attest:
Wilson T. McClellan, Superintendent
Calhoun County Schools
Legal Notice
IN THE CIRCUIT COURT OF THE 14TH JUDICIAL CIRCUIT IN AND FOR CALHOUN COUNTY,
FLORIDA
CASE NO.2009-0066-DR
Bonnie Torres,
Petitioner
and
Luis Torres,
Respondent
NOTICE OF ACTION FOR DISSOLUTION
OF MARRIAGE
To: Luis Torres
Address: 1511 168th Street, Pembroke Pines, Fl. 33028
YOU ARE NOTIFIED that an action has been filed against you and that you are required to serve a copy of your written defenses, if any, to it on Bonnie Torres, whose address is P.O. Box 1003, Blountstown, FL 32424 on or before August 7, 2009, and file the original with the clerk of this Court at 20859 Central Ave., E., Room 130, Blountstown, FL 32424, before service on Petitioner or immediately thereafter. If you fail to do so, a default may be entered against you for the relief demanded in the petition.
Copies of all court documents in this case, including orders, are available at the Clerk of the Circuit Court’s office. You may review these documents upon request.
You must keep the Clerk of the Circuit Court’s office notified of your current address. (You may file Notice of Current Address, Florida Supreme Court Approved Family Law form 12.915.) Future papers in this lawsuit will be mailed to the address on record at the clerk’s office.
WARNING: Rule 12.285, Florida Family Law Rules of Procedures, requires certain automatic disclosure of documents and information. Failure to comply can result in sanctions, including dismissal or striking of pleadings.
Dated this July 2, 2009.
Ruth W. Attaway,
Clerk of the Circuit Court
Legal Notice
IN THE CIRCUIT COURT OF THE 14TH JUDICIAL CIRCUIT IN AND FOR CALHOUN COUNTY,
FLORIDA
CASE NO.2009-0163-DR
Gloria Jean Juarez,
Petitioner
and
Benito Gutierrez Juarez,
Respondent
NOTICE OF ACTION FOR DISSOLUTION
OF MARRIAGE
To: Benito Gutierrez Juarez,
Address: P.O. Box 280053, Tampa, FL 33682
YOU ARE NOTIFIED that an action has been filed against you and that you are required to serve a copy of your written defenses, if any, to it on Gloria Jean Juarez, whose address is P.O. Box 244, Blountstown, FL 32424 on or before August 7, 2009, and file the original with the clerk of this Court at 20859 Central Ave., E., Room 130, Blountstown, FL 32424, before service on Petitioner or immediately thereafter. If you fail to do so, a default may be entered against you for the relief demanded in the petition.
Copies of all court documents in this case, including orders, are available at the Clerk of the Circuit Court’s office. You may review these documents upon request.
You must keep the Clerk of the Circuit Court’s office notified of your current address. (You may file Notice of Current Address, Florida Supreme Court Approved Family Law form 12.915.) Future papers in this lawsuit will be mailed to the address on record at the clerk’s office.
WARNING: Rule 12.285, Florida Family Law Rules of Procedures, requires certain automatic disclosure of documents and information. Failure to comply can result in sanctions, including dismissal or striking of pleadings.
Dated this July 8, 2009.
Ruth W. Attaway,
Clerk of the Circuit Court
Legal Notice
CALHOUN COUNTY PROJECT # 014.140
CHIPOLA ROAD IMPROVEMENTS
NOTICE TO RECEIVE SEALED BIDS
The Calhoun County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing the following project:
CALHOUN COUNY
CHIPOLA ROAD IMPROVEMENTS
Plans and specifications can be obtained at Preble-Rish, Inc., 20684 Central Ave. East, Blountstown, FL 32424; (850) 674-3300. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
Completion date for these projects will be 180 days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $500.00 per day.
All bidders must be pre-qualified with Florida Department of Transportation per Section 2-1 f the FDOT Standards and Specifications of Road and Bridge Construction, latest edition.
Please indicate on the envelope that this is a sealed bid, the bid number and what the bid is for.
Bids will be received until 2:00 p.m. (C.T.), on August 18, 20 09 , at the Calhoun County Clerk’s Office, Calhoun County Courthouse, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424, and will be opened and read aloud on August 18, 20 09 , at 5:00 p.m.(C.T.).
Cost for Plans and Specifications will be $ 100.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC.
The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Calhoun County.
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT OF THE STATE OF FLORIDA,
IN AND FOR CALHOUN COUNTY
CIVIL DIVISION
CASE NO: 02009-CA-61
TAYLOR, BEAN & WHITAKER MORTGAGE CORP.,
Plaintiff,
-vs-
TERESA BODIFORD, THE UNKNOWN SPOUSE OF TERESA BODIFORD, WILEY D. TOLBERT; STEVEN BODIFORD; THE UNKNOWN SPOUSE OF STEVEN BODIFORD; OF LIVING, INCLUDING ANY UNKNOWN SPOUSE OF SAID DEFENDANT(S), IF REMARRIED, AND IF DECEASED, THE RESPECTIVE UNKNOWN HEIRS, DEVISEES, GRANTEES, ASSIGNEES, CREDITORS, LIENORS, AND TRUSTEES, AND ALL OTHER PERSONS CLAIMING BY, THROUGH, UNDER OR AGAINST THE NAMED DEFENDANT(S); UNKNOWN TENANT #1; UNKNOWN TENANT #2.
Defendant(s)
NOTICE OF SALE
Notice is hereby given that, pursuant to a Final Summary Judgment of Foreclosure entered in the above-styled cause, in the Circuit Court of Calhoun County Florida, I will sell the property situate in Calhoun County, Florida, described as:
Begin at the Northwest Corner of the Southwest 1/4 of the Northwest 1/4 of Section 4, Township 2 North, Range 9 West, Calhoun County, Florida; thence run East 830 feet; thence run south 530 feet; thence run West 830 feet; thence north 530 feet; back to the POINT OF BEGINNING.
A/K/A
14893 NW Sam Duncan Road
Altha, FL 32421
at public sale, to the highest and best bidder, for cash, Calhoun County Courthouse, 20859 SE Central Avenue East, Blountstown, FL 32424 at 11:00 A.M. CST on August 20, 2009.
DATED at CALHOUN County this 20th day of July, 2009.
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the lis pendens, must filer a claim within 60 days after the sale.
WITNESS my hand and seal of this court on the 13th day of May, 2009.
Ruth W. Attaway
Clerk of Court
In accordance with the American with Disabilities Act of 1990, persons needing accommodation to participate in this proceeding should contact the ASA Coordinator no later than seven (7) days prior to the proceedings. If hearing impaired, please call (800) 955-9771 (TDD) or (800) 59-8770 (voice), via Florida Relay Service
Law Offices of Daniel C. Consuegra
9204 King Palm Drive
Tampa, FL 33619-1328
Tel: (813) 915-8660
Fax: (813) 915-0559
Attorney for Plaintiff
Legal Notice
CITY OF BLOUNTSTOWN -
MISCELLANEOUS STRIPING
NOTICE TO RECEIVE SEALED BIDS
The City of Blountstown will receive sealed bids from any qualified person, company or corporation interested in constructing:
CITY OF BLOUNTSTOWN - MISCELLANEOUS STRIPING
This project shall consist of miscellaneous striping on various roads within the City of Blountstown.
The RFP package can be obtained at Blountstown City Hall located at 20591 Central Avenue West, Blountstown Florida 32424 (850) 674-5488. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
Completion date for these projects will be 90 days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day.
Please indicate on the envelope that this is a sealed bid, the bid number and what the bid is for.
Bids will be received until 2:00 p.m. Eastern Time, on September 8 , 2009, at the Blountstown City Hall located at 20591 Central Avenue West, Blountstown Florida 32424 (850) 674-5488, and will be opened and read aloud on September 8 , 2009, at 6:00 p.m. Central Time. The public is invited to attend.
Cost for Plans and Specifications will be $ 25.00 per set and is non-refundable. Checks should be made payable to the City of Blountstown.
The City of Blountstown reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the lowest responsive and responsible bid.
If you have any questions, please call James Woods at (850) 674-5488.
Legal Notice
BLOUNTSTOWN TRAIL IMPROVEMENTS PROJECT #013.014
NOTICE TO RECEIVE SEALED BIDS
The City of Blountstown will receive sealed bids from any qualified person, company or corporation interested in providing the requested services for the following project:
BLOUNTSTOWN TRAIL IMPROVEMENTS
The project is located at the Depot Trailhead in Blountstown, Florida. The project improvements will include the construction of a new restroom, pavilion, playground equipment and concrete sidewalk.
Plans and specifications can be obtained at Preble-Rish, Inc., 20684 Central Avenue, East, Blountstown, Florida 32424, (850)674-3300. Cost for plans and specifications will be $ 75.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC.
The substantial completion date for this project will be 60 days from the date of the Notice to Proceed presented to the successful bidder and fully complete with 90 days from the date of the Notice to Proceed.
Liquidated damages for failure to complete the project on the specified date will be set at $250.00 per day.
Please indicate on the envelope that this is a sealed bid, for the “BLOUNTSTOWN TRAIL IMPROVEMENTS”
Bids will be received until _3_p.m. Central Standard Time, on August 25, 2009, at the City of Blountstown City Hall, 20591 Central Avenue West, Blountstown, Florida 32424, and will be opened and read at that time on the same date during their regularly scheduled meeting. The City of Blountstown is an Equal Opportunity Employer/Handicapped Accessible/Fair Housing Jurisdiction.
The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. A Bid Bond in the amount of 5% of the Bid shall accompany the Bid. The City of Blountstown reserves the right to reject any and all bids. All Bids shall remain firm for a period of sixty days after the opening.
All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida.
AD run date: August 5th, 2009
Legal Notice
R & R WAREHOUSES
NOTICE OF SALE
On August 17, 2009, at 10:00 a.m. (CST), R & R Warehouses will dispose of the contents of seven (7) storage units from Blountstown and four (4) storage units from Bristol at 19300 SR 20 W. (850) 674-4700.
The units are believed to contain household and/or personal property of the following tenants:
Drew Bennett
Jerry Brown
Antonio Charleston
Deidre Daughtrey
Ricky Davis
Tammy Fisher
Coretha Jones
Marvadean Kirkland
Jackie Lytle
Jacquelyn Mango
Cherlyn Morgan
All units not paid in full by this date will be disposed of. THERE WILL BE NO AUCTION!!
The Calhoun County School Board proposes to introduce and amend policies for Calhoun County Schools as follows:
ADMINISTRATIVE PROCEDURES ACT
CALHOUN COUNTY SCHOOLS
CHAPTER 5-STUDENTS
CHAPTER 6-HUMAN RESOURCES
Introducing and Amending Policy:
Policy 5.14 Homeless Students
Policy 5.64 Nutrition, Physical Fitness, and Wellness
Policy 6.531 DROP
Policy 6.81 Social Security Number Collection and Usage
Policy 6.912 Terminal Sick Leave and Vacation Pay
The entire proposals are available for viewing at the School Superintendent’s Office, Room G-20, Calhoun County Court House, Blountstown, Florida.
A hearing will be held on the above policies in the Courthouse in Blountstown, Florida at the Regular School Board meeting on Tuesday, August 11, 2009 at 5:00 p.m.
Kelly King, Chairperson
Calhoun County School Board
Attest:
Wilson T. McClellan, Superintendent
Calhoun County Schools
Legal Notice
IN THE CIRCUIT COURT OF THE 14TH JUDICIAL CIRCUIT IN AND FOR CALHOUN COUNTY,
FLORIDA
CASE NO.2009-0066-DR
Bonnie Torres,
Petitioner
and
Luis Torres,
Respondent
NOTICE OF ACTION FOR DISSOLUTION
OF MARRIAGE
To: Luis Torres
Address: 1511 168th Street, Pembroke Pines, Fl. 33028
YOU ARE NOTIFIED that an action has been filed against you and that you are required to serve a copy of your written defenses, if any, to it on Bonnie Torres, whose address is P.O. Box 1003, Blountstown, FL 32424 on or before August 7, 2009, and file the original with the clerk of this Court at 20859 Central Ave., E., Room 130, Blountstown, FL 32424, before service on Petitioner or immediately thereafter. If you fail to do so, a default may be entered against you for the relief demanded in the petition.
Copies of all court documents in this case, including orders, are available at the Clerk of the Circuit Court’s office. You may review these documents upon request.
You must keep the Clerk of the Circuit Court’s office notified of your current address. (You may file Notice of Current Address, Florida Supreme Court Approved Family Law form 12.915.) Future papers in this lawsuit will be mailed to the address on record at the clerk’s office.
WARNING: Rule 12.285, Florida Family Law Rules of Procedures, requires certain automatic disclosure of documents and information. Failure to comply can result in sanctions, including dismissal or striking of pleadings.
Dated this July 2, 2009.
Ruth W. Attaway,
Clerk of the Circuit Court
Legal Notice
IN THE CIRCUIT COURT OF THE 14TH JUDICIAL CIRCUIT IN AND FOR CALHOUN COUNTY,
FLORIDA
CASE NO.2009-0163-DR
Gloria Jean Juarez,
Petitioner
and
Benito Gutierrez Juarez,
Respondent
NOTICE OF ACTION FOR DISSOLUTION
OF MARRIAGE
To: Benito Gutierrez Juarez,
Address: P.O. Box 280053, Tampa, FL 33682
YOU ARE NOTIFIED that an action has been filed against you and that you are required to serve a copy of your written defenses, if any, to it on Gloria Jean Juarez, whose address is P.O. Box 244, Blountstown, FL 32424 on or before August 7, 2009, and file the original with the clerk of this Court at 20859 Central Ave., E., Room 130, Blountstown, FL 32424, before service on Petitioner or immediately thereafter. If you fail to do so, a default may be entered against you for the relief demanded in the petition.
Copies of all court documents in this case, including orders, are available at the Clerk of the Circuit Court’s office. You may review these documents upon request.
You must keep the Clerk of the Circuit Court’s office notified of your current address. (You may file Notice of Current Address, Florida Supreme Court Approved Family Law form 12.915.) Future papers in this lawsuit will be mailed to the address on record at the clerk’s office.
WARNING: Rule 12.285, Florida Family Law Rules of Procedures, requires certain automatic disclosure of documents and information. Failure to comply can result in sanctions, including dismissal or striking of pleadings.
Dated this July 8, 2009.
Ruth W. Attaway,
Clerk of the Circuit Court
Legal Notice
CALHOUN COUNTY PROJECT # 014.140
CHIPOLA ROAD IMPROVEMENTS
NOTICE TO RECEIVE SEALED BIDS
The Calhoun County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing the following project:
CALHOUN COUNY
CHIPOLA ROAD IMPROVEMENTS
Plans and specifications can be obtained at Preble-Rish, Inc., 20684 Central Ave. East, Blountstown, FL 32424; (850) 674-3300. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
Completion date for these projects will be 180 days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $500.00 per day.
All bidders must be pre-qualified with Florida Department of Transportation per Section 2-1 f the FDOT Standards and Specifications of Road and Bridge Construction, latest edition.
Please indicate on the envelope that this is a sealed bid, the bid number and what the bid is for.
Bids will be received until 2:00 p.m. (C.T.), on August 18, 20 09 , at the Calhoun County Clerk’s Office, Calhoun County Courthouse, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424, and will be opened and read aloud on August 18, 20 09 , at 5:00 p.m.(C.T.).
Cost for Plans and Specifications will be $ 100.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC.
The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Calhoun County.
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT OF THE STATE OF FLORIDA,
IN AND FOR CALHOUN COUNTY
CIVIL DIVISION
CASE NO: 02009-CA-61
TAYLOR, BEAN & WHITAKER MORTGAGE CORP.,
Plaintiff,
-vs-
TERESA BODIFORD, THE UNKNOWN SPOUSE OF TERESA BODIFORD, WILEY D. TOLBERT; STEVEN BODIFORD; THE UNKNOWN SPOUSE OF STEVEN BODIFORD; OF LIVING, INCLUDING ANY UNKNOWN SPOUSE OF SAID DEFENDANT(S), IF REMARRIED, AND IF DECEASED, THE RESPECTIVE UNKNOWN HEIRS, DEVISEES, GRANTEES, ASSIGNEES, CREDITORS, LIENORS, AND TRUSTEES, AND ALL OTHER PERSONS CLAIMING BY, THROUGH, UNDER OR AGAINST THE NAMED DEFENDANT(S); UNKNOWN TENANT #1; UNKNOWN TENANT #2.
Defendant(s)
NOTICE OF SALE
Notice is hereby given that, pursuant to a Final Summary Judgment of Foreclosure entered in the above-styled cause, in the Circuit Court of Calhoun County Florida, I will sell the property situate in Calhoun County, Florida, described as:
Begin at the Northwest Corner of the Southwest 1/4 of the Northwest 1/4 of Section 4, Township 2 North, Range 9 West, Calhoun County, Florida; thence run East 830 feet; thence run south 530 feet; thence run West 830 feet; thence north 530 feet; back to the POINT OF BEGINNING.
A/K/A
14893 NW Sam Duncan Road
Altha, FL 32421
at public sale, to the highest and best bidder, for cash, Calhoun County Courthouse, 20859 SE Central Avenue East, Blountstown, FL 32424 at 11:00 A.M. CST on August 20, 2009.
DATED at CALHOUN County this 20th day of July, 2009.
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the lis pendens, must filer a claim within 60 days after the sale.
WITNESS my hand and seal of this court on the 13th day of May, 2009.
Ruth W. Attaway
Clerk of Court
In accordance with the American with Disabilities Act of 1990, persons needing accommodation to participate in this proceeding should contact the ASA Coordinator no later than seven (7) days prior to the proceedings. If hearing impaired, please call (800) 955-9771 (TDD) or (800) 59-8770 (voice), via Florida Relay Service
Law Offices of Daniel C. Consuegra
9204 King Palm Drive
Tampa, FL 33619-1328
Tel: (813) 915-8660
Fax: (813) 915-0559
Attorney for Plaintiff
Legal Notice
CITY OF BLOUNTSTOWN -
MISCELLANEOUS STRIPING
NOTICE TO RECEIVE SEALED BIDS
The City of Blountstown will receive sealed bids from any qualified person, company or corporation interested in constructing:
CITY OF BLOUNTSTOWN - MISCELLANEOUS STRIPING
This project shall consist of miscellaneous striping on various roads within the City of Blountstown.
The RFP package can be obtained at Blountstown City Hall located at 20591 Central Avenue West, Blountstown Florida 32424 (850) 674-5488. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
Completion date for these projects will be 90 days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day.
Please indicate on the envelope that this is a sealed bid, the bid number and what the bid is for.
Bids will be received until 2:00 p.m. Eastern Time, on September 8 , 2009, at the Blountstown City Hall located at 20591 Central Avenue West, Blountstown Florida 32424 (850) 674-5488, and will be opened and read aloud on September 8 , 2009, at 6:00 p.m. Central Time. The public is invited to attend.
Cost for Plans and Specifications will be $ 25.00 per set and is non-refundable. Checks should be made payable to the City of Blountstown.
The City of Blountstown reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the lowest responsive and responsible bid.
If you have any questions, please call James Woods at (850) 674-5488.
Legal Notice
BLOUNTSTOWN TRAIL IMPROVEMENTS PROJECT #013.014
NOTICE TO RECEIVE SEALED BIDS
The City of Blountstown will receive sealed bids from any qualified person, company or corporation interested in providing the requested services for the following project:
BLOUNTSTOWN TRAIL IMPROVEMENTS
The project is located at the Depot Trailhead in Blountstown, Florida. The project improvements will include the construction of a new restroom, pavilion, playground equipment and concrete sidewalk.
Plans and specifications can be obtained at Preble-Rish, Inc., 20684 Central Avenue, East, Blountstown, Florida 32424, (850)674-3300. Cost for plans and specifications will be $ 75.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC.
The substantial completion date for this project will be 60 days from the date of the Notice to Proceed presented to the successful bidder and fully complete with 90 days from the date of the Notice to Proceed.
Liquidated damages for failure to complete the project on the specified date will be set at $250.00 per day.
Please indicate on the envelope that this is a sealed bid, for the “BLOUNTSTOWN TRAIL IMPROVEMENTS”
Bids will be received until _3_p.m. Central Standard Time, on August 25, 2009, at the City of Blountstown City Hall, 20591 Central Avenue West, Blountstown, Florida 32424, and will be opened and read at that time on the same date during their regularly scheduled meeting. The City of Blountstown is an Equal Opportunity Employer/Handicapped Accessible/Fair Housing Jurisdiction.
The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. A Bid Bond in the amount of 5% of the Bid shall accompany the Bid. The City of Blountstown reserves the right to reject any and all bids. All Bids shall remain firm for a period of sixty days after the opening.
All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida.
AD run date: August 5th, 2009
Legal Notice
R & R WAREHOUSES
NOTICE OF SALE
On August 17, 2009, at 10:00 a.m. (CST), R & R Warehouses will dispose of the contents of seven (7) storage units from Blountstown and four (4) storage units from Bristol at 19300 SR 20 W. (850) 674-4700.
The units are believed to contain household and/or personal property of the following tenants:
Drew Bennett
Jerry Brown
Antonio Charleston
Deidre Daughtrey
Ricky Davis
Tammy Fisher
Coretha Jones
Marvadean Kirkland
Jackie Lytle
Jacquelyn Mango
Cherlyn Morgan
All units not paid in full by this date will be disposed of. THERE WILL BE NO AUCTION!!
Trackbacks
Trackback specific URI for this entry
No Trackbacks