Legal Notices For 05-21-09
Legal Notices For 05-21-09
Legal Notice
NOTICE TO RECEIVE SEALED BIDS
The Calhoun County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing:
SAM ATKINS PARK - RECREATION FIELD
LIGHTING
Plans and specifications can be obtained at Preble-Rish, Inc. 324 Marina Drive, Port St. Joe, Florida 32456, (850) 227-7200. The bid must conform to Section 287.133(3) Florida Statutes on public entity crimes.
This project consists of recreation field lighting at Sam Atkins Park.
Completion date for these projects will be 90 days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $200 per day.
Please indicate on the envelope that this is a sealed bid for RECREATION FIELD LIGHTING AT SAM ATKINS PARK.
Bids will be received until 12:00 p.m. CST on Tuesday, June 2, 2009, at the Calhoun County Clerk’s Office, Calhoun County Courthouse, 20859 Central Avenue East, Room 130, Blountstown, FL 32424, and will be opened and read aloud on Tuesday, June 2, 2009, at 2:00 p.m. CST.
Cost for Plans and Specifications will be $25.00 per set and is non-refundable. Checks should be made payable to Preble-Rish, Inc.
The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Calhoun County.
If you have any questions, please call Donald Stanley at (850) 643-2771 or Kim Tanner at (850) 674-4545.
Legal Notice
The Calhoun County School Board proposes to introduce and amend policies for Calhoun County Schools as follows:
ADMINISTRATIVE PROCEDURES ACT
CALHOUN COUNTY SCHOOLS
CHAPTER 2-SCHOOL BOARD GOVERANCY AND ORGANIZATION
CHAPTER 6-HUMAN RESOURCES
Introducing and Amending Policy:
Policy 6.13-Years of Service
Policy 6.531-DROP
Policy 6.92-Health Insurance Premiums
Policy 6.912-Terminal Sick Leave and Vacation Pay
Policy 2.221-Public Participation During Board Meetings
Most of these policy changes are necessitated by changes in statute citations by the State of Florida. The entire proposals are available for viewing at the School Superintendent’s Office, Room G-20, Calhoun County Court House, Blountstown, Florida.
A hearing will be held on the above policies in the Courthouse in Blountstown, Florida at the Regular School Board meeting on Tuesday, June 9, 2009 at 5:00 p.m.
Kelly King, Chairperson
Calhoun County School Board
Attest:
Wilson T. McClellan, Superintendent
Calhoun County Schools
“An Equal Opportunity Employer”
Legal Notice
IN THE CIRCUIT COURT FOR CALHOUN
COUNTY FLORIDA,
PROBATE DIVISION
File No. 09-28 PR
IN RE: ESTATE OF
GARY SAVAGE,
Deceased.
NOTICE TO CREDITORS
The administration of the estate of GARY SAVAGE, deceased, whose date of death was October 2, 2008, File Number 09-28 PR, is pending in the Circuit Court for Calhoun County, Florida, Probate Division, the address of which is 20859 Central Ave., E., Blountstown, Florida 32424. The names and addresses of the personal representative and the personal representative’s attorney are set forth below.
All creditors of the decedent and other persons having claims or demands against decedent’s estate, including unmatured, contingent or unliquidated claims, on whom a copy of this notice is served mule file their claims with this court WITHIN THE LATER OF THREE MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE OR THIRTY DAYS AFTER THE DATE OF SERVICE OF A COPY OF THIS NOTICE ON THEM.
All other creditors of the decedent and persons having claims or demands against the decedent’s estate including unmatured, contingent or unliquidated claims, must file their claims with this court WITHIN THREE MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE.
ALL CLAIMS, DEMANDS AND OBJECTIONS NOT SO FILED WILL BE FOREVER BARRED.
The date of the first publication of this Notice is May 6, 2009.
Personal Representative:
JAMES SAVAGE
2312 Coach Road
Argyle, NY 12809
DAMIEN SAVAGE
47 Saratoga Ave.
S. Glens Falls. NY 12803
Attorney for Personal Representative:
DENNIS J. O’CONNOR, ESQ.
Florida Bar No. 643297
MCPHILLIPS, FITZGERALD, CULLUM, L.L.P.
9165 Park Drive
Miami Shores, FL 33308
Telephone: (305) 751-8556
Legal Notice
IN THE CIRCUIT COURT OF THE
FOURTEENTH JUDICIAL CIRCUIT
IN AND FOR CALHOUN COUNTY, FLORIDA
CIVIC ACTION
CASE NO.: 07-2008-CA-000328
CHASE HOME FINANCE LLC,
Plaintiff,
-vs-
THE UNKNOWN HEIRS, DEVISEES,
GRANTEES, ASSIGNEES, LIENORS,
CREDITORS, TRUSTEES, OR OTHER
CLAIMANTS, CLAIMING BY,
THROUGH, UNDER, OR AGAINST DANIEL
COHEE, A/K/A DANIEL EDMUND COHEE
A/K/A DANIEL EDMOND COHEE, DECEASED,
et al,
Defendant(s)
NOTICE OF ACTION
TO;
MICHELLE LEE COHEE, AS AN HEIR OF THE ESTATE OF DANIEL COHEE A/K/A DANIEL EDMUND COHEE A/K/A DANIEL EDMOND COHEE, DECEASED
LAST KNOWN ADDRESS: 265 SUNSHINE SPRINGS COURT, HENDERSON, NV 89014
CURRENT ADDRESS: UNKNOWN
YOU ARE NOTIFIED that an action to foreclose a mortgage on the following property in CALHOUN County, Florida:
COMMENCE AT THE SOUTHWEST CORNER OF THE NORTHEAST QUARTER OF SECTION 6, TOWNSHIP 1 SOUTH, RANGE 8 WEST, CALHOUN COUNTY, FLORIDA AND RUN THENCE SOUTH 89 DEGREES 22 MINUTES 33 SECONDS EAST ALONG THE SOUTHERLY BOUNDARY OF SAID NORTHEAST QUARTER A DISTANCE OF 26.67 FEET TO THE EASTERLY RIGHT OF WAY BOUNDARY OF FAIRCLOTH ROAD (80 FOOT RIGHT OF WAY) AND THE POINT OF BEGINNING. FROM SAID POINT OF BEGINNING THENCE NORTH 00 DEGREES 39 MINUTES 51 SECONDS EAST ALONG SAID EASTERLY RIGHT OF WAY BOUNDARY A DISTANCE OF 330.99 FEET TO THE NORTHERLY BOUNDARY OF THE SOUTH HALF OF THE SOUTHWEST QUARTER OF THE SOUTHWEST QUARTER OF SAID NORTHEAST QUARTER; THENCE SOUTH 89 DEGREES 22 MINUTES 21 SECONDS EAST ALONG SAID NORTHERLY BOUNDARY A DISTANCE OF 130.00 FEET; THENCE SOUTH 00 DEGREES 39 MINUTES 51 SECONDS WEST 330.98 FEET TO THE AFORESAID SOUTHERLY BOUNDARY OF THE NORTHEAST QUARTER; THENCE NORTH 89 DEGREES 22 MINUTES 33 SECONDS WEST ALONG SAID SOUTHERLY BOUNDARY A DISTANCE OF 130.00 FEET TO THE POINT OF BEGINNING.
TOGETHER WITH 1 2003 FLEETWOOD DOUBLEWIDE MOBILE HOME BEARING ID NO. GAFL275A74414-CD21 AND GAFL275B74414-CD21, LYING AND BEING SITUATE THEREON. TOGETHER WITH THAT CERTAIN MOBILE HOME LOCATED THEREON AS A FIXTURE AND APPURTENANCE THERETO.
has been filed against you and you are required to serve a copy of your written defenses within 30 days after the first publication, if any, on Florida Default Law Group, P.L., Plaintiff’s attorney, whose address is 9119 Corporate Lake Drive, Suite 300, Tampa, Florida 33634, and file the original with this Court either before service on Plaintiff’s attorney or immediately thereafter; otherwise a default will be entered against you for the relief demanded in the Complaint or petition.
This notice shall be published each week for two consecutive weeks in The County Record.
WITNESS my hand and the seal of this Court on this 7th day of May, 2009.
RUTH W. ATTAWAY
CLERK OF THE COURT
Legal Notice
IN THE CIRCUIT COURT OF THE
FOURTEENTH JUDICIAL CIRCUIT
IN AND FOR CALHOUN COUNTY, FLORIDA
CIVIC ACTION
CASE NO.: 07-2008-CA-000272
CHASE HOME FINANCE LLC,
Plaintiff,
-vs-
KRISTINA L. SUTHERLAND, et al.,
Defendant(s)
NOTICE OF FORECLOSURE SALE
NOTICE IS HEREBY GIVEN pursuant to a Final Judgment of Mortgage Foreclosure dated May 06, 2009 and entered in Case No. 07-2008-CA-000272 of the Circuit Court of the FOURTEENTH Judicial Circuit in and for CALHOUN County, Florida where CHASE HOME FINANCE LLC, is the Plaintiff and KRISTINE L. SUTHERLAND; BARBARA L. SUTHERLAND; AND ANY AND ALL UNKNOWN PARTIES CLAIMING BY, THROUGH, UNDER, AND AGAINST THE HEREIN NAMED INDIVIDUAL DEFENDANT(S) WHO ARE NOT KNOWN TO BE DEAD OR ALIVE, WHETHER SAID UNKNOWN PARTIES MAY CLAIM AN INTEREST AS SPOUSE, HEIRS, DEVISEES, GRANTEES, OR OTHER CLAIMANTS; are the Defendants, I will sell to the highest and best bidder for cash at LOBBY OF THE CALHOUN COUNTY COURTHOUSE at 11:00 AM CST, on the 25th day of June, 2009, the following described property as set forth in said Final Judgment:
COMMENCE AT A 6 INCH SQUARE CONCRETE MONUMENT MARKING THE SOUTHWEST CORNER OF SECTION 35, TOWNSHIP 2 NORTH, RANGE 11 WEST, CALHOUN COUNTY, FLORIDA AND RUN THENCE NORTH 89 DEGREES 22 MINUTES 27 SECONDS WEST ALONG THE SOUTHERLY BOUNDARY OF SAID SECTION 35 A DISTANCE OF 1647.39 FEET TO THE SOUTHEAST CORNER OF THE WEST HALF OF THE SOUTHEAST QUARTER OF THE SOUTHWEST CORNER OF THE SOUTHEAST QUARTER OF SAID SECTION 35 AND THE POINT OF BEGINNING. FROM SAID POINT OF BEGINNING THENCE NORTH 00 DEGREES 28 MINUTES 28 SECONDS WEST 134.97 FEET THENCE NORTH 89 DEGREES 34 MINUTES 05 SECONDS WEST 329.83 FEET THENCE SOUTH 00 DEGREES 38 MINUTES 06 SECONDS EAST 133.86 FEET TO SAID SOUTHERLY BOUNDARY; THENCE SOUTH 89 DEGREES 22 MINUTES 27 SECONDS EAST ALONG SAID SOUTHERLY BOUNDARY A DISTANCE OF 329.48 FEET TO THE POINT OF BEGINNING. WHICH INCLUDES THAT CERTAIN 2007 KING MODEL NO. 44E3H, NOBILITY MANUFACTURED HOME, SERIAL NO. N813072A/N813072B, WHICH IS ATTACHED AND MADE A PART OF THE REAL PROPERTY. WHICH, BY INTENTION OF THE PARTIES AND UPON RETIREMENT OF THE CERTIFICATE OF TITLE AS PROVIDED IN 319.261 FLORIDA, STATUTES, SHALL CONSTITUTE A PART OF THE REALTY AND SHALL PASS WITH IT.
A/K/A 5142 NW MILLER ROAD, ALTHA, FL 324210000
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the Lis pendens must file a claim within sixty (60) days after the sale.
WITNESS MY HAND and the seal of this Court on May 8, 2009.
Ruth W. Attaway
Clerk of the Circuit Court
WITNESS MY HAND and the sale of this Court on March 5, 2008.
Ruth W. Attaway
Clerk of the Circuit Court
March 12, 19, 2008
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT OF THE STATE OF FLORIDA,
IN AND FOR CALHOUN COUNTY
CIVIL DIVISION
CASE NO: 08-266-CA
CITIMORTGAGE, INC.,
Plaintiff,
-vs-
SAMUEL GEORGE HAYSLIP, III A/K/A SAMUEL HAYSLIP; UNKNOWN SPOUSE OF SAMUEL GEORGE HAYSLIP, III A/K/A SAMUEL HAYSLIP; ANGELINA ALICE HAYSLIP; UNKNOWN SPOUSE OF ANGELINA ALICE HAYSLIP; IF LIVING, INCLUDING ANY UNKNOWN SPOUSE OF SAID DEFENDANT(S), IF REMARRIED, AND IF DECEASED, THE RESPECTIVE UNKNOWN HEIRS, DEVISEES, GRANTEES, ASSIGNEES, CREDITORS, LIENORS, AND TRUSTEES, AND ALL OTHER PERSONS CLAIMING BY, THROUGH, UNDER OR AGAINST THE NAMED DEFENDANT(S); UNKNOWN TENANT #1; UNKNOWN TENANT #2;
Defendant(s)
NOTICE OF SALE
Notice is hereby given that, pursuant to a Final Summary Judgment of Foreclosure entered in the above-styled cause, in the Circuit Court of Calhoun County Florida, I will sell the property situate in Calhoun County, Florida, described as:
COMMENCE AT THE INTERSECTION OF THE CENTER L INE OF SR #274 AND THE EAST LINE OF SECTION 16, TOWNSHIP 2 NORTH, RANGE 9 WEST, CALHOUN COUNTY, FLORIDA (DEPARTMENT OF TRANSPORTATION STATION 281 + 29.07); THENCE NORTH 89 DEGREES 17 MINUTES 57 SECONDS WEST ALONG SAID CENTER LINE 1815.44 FEET TO THE P.T. (STATION 263. + 13.63); THENCE CONTINUE NORTH 89 DEGREES 17 MINUTES 57 SECONDS WEST 383.88 FEET TO A CONCRETE MONUMENT ON THE NORTHERLY RIGHT OF WAY OF SAID, ROAD AND CALL THIS THE POINT OF BEGINNING; THENCE CONTINUE NORTH 89 DEGREES 17 MINUTES 57 SECONDS WEST 651.20 FEET TO A CONCRETE MONUMENT; THENCE SOUTH 08 DEGREES 32 MINUTES 03 SECONDS WEST 200.00 FEET TO A CONCRETE MONUMENT; THENCE SOUTH 03 DEGREES 04 MINUTES 48 SECONDS WEST 171.27 FEET TO A CONCRETE MONUMENT ON THE WESTERLY RIGHT OF WAY OF SR #274; THENCE NORTH 55 DEGREES 46 MINUTES 21 SECONDS EAST ALONG SAID RIGHT OF WAY 228.45 FEET TO THE P.C. OF A CURVE (D.O.T. STATION 254 +39.05); THENCE CONTINUE ALONG SAID RIGHT OF WAY A CONCAVE TOWARDS THE RIGHT HAVING A DELTA ANGLE OF 18 DEGREES 42 MINUTES 30 SECONDS A RADIUS OF 1699.28 FEET: AN ARC DISTANCE OF 554.85 FEET TO THE POINT OF BEGINNING.
A/K/A
15006 NW COUNTY ROAD #274
ALTHA, FL 32421
at public sale, to the highest and best bidder, for cash, Calhoun County Courthouse, 20859 SE Central Avenue East, Blountstown, FL 32424 at 11:00 A.M. CST on June 11, 2009.
DATED at CALHOUN County this 30th day of July, 2008.
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the lis pendens, must filer a claim within 60 days after the sale.
WITNESS my hand and seal of this court on the 6th day of May, 2009.
Ruth W. Attaway
Clerk of Court
In accordance with the American with Disabilities Act of 1990, persons needing accommodation to participate in this proceeding should contact the ASA Coordinator no later than seven (7) days prior to the proceedings. If hearing impaired, please call (800) 955-9771 (TDD) or (800) 59-8770 (voice), via Florida Relay Service
Law Offices of Daniel C. Consuegra
9204 King Palm Drive
Tampa, FL 33619-1328
Tel: (813) 915-8660
Fax: (813) 915-0559
Attorney for Plaintiff
Legal Notice
INVITATION TO BID
Sealed bids will be received by the Calhoun County School Board until 5:00 P.M., CDT, Tuesday, June 9, 2009, for the purchase of the following:
LP Gas for use in lunchrooms and schools of Calhoun County.
Gasoline and Diesel for use in the operation of public vehicles, school buses and school plants.
Any additional information or bid forms required may be obtained at the Office of the School Superintendent, 20859 Central Ave. E., Rm. G-20, Blountstown, Florida. Bid forms must be used by each bidder submitting a bid. Otherwise bids will not be considered.
Any bid submitted after the specified hour and date will not be opened or considered. The Board accepts no responsibility for mailed proposals that arrive at the Superintendent’s Office after the above stated time, even though the envelope may reflect a postmark prior to the above date.
The Board reserves the right to accept or reject any or all bids. The decision of the Board will be final. No bid may be withdrawn by any bidder for a period of thirty (30) days after bids are opened.
Kelly King, Chairman
Calhoun County School Board
ATTEST:
Tommy McClellan, Superintendent
Calhoun County Schools
Legal Notice
Public Auction
Mallory Towing and Recovery Inc. will hold a public auction on, May 29, 2009 at 2:00 (P.M.) on a:
1996 Hyundai, 4 Door, White in Color
Vin#KMHJF24MXTU199594
Auction will be held at Mallory Towing and Recovery Inc. at 17311 NE Pear Street, in Blountstown FL., 850-674-2869.
Mallory Towing and Recovery Inc. reserves the right to reject any and all bids.
Legal Notice
State of Florida
Department of Environmental Protection
NOTICE OF APPLICATION
The Department announces receipt of an application for a permit to create a 3,030-acre mitigation bank known as the Bear Creek Mitigation Bank in four phases. The application is submitted by Mr. Tom Odom, authorized agent, Mitigation Resources, LLC, 713 Montrose St., Clermont, FL 34711 for the applicant Bear Creek Timber, LLC represented by Matthew Whitley. The mitigation plan includes the restoration or enhancement and preservation of onsite uplandflatwoods and bay swamp communities to earn credits with the potential to offset impacts to wetland resources within the service area. Enhancement will be accomplished by the construction of ditch blocks and low water crossings and by the removal of inappropriate vegetation, establishment of prescribed fires, and long term management. This project is located in Sections 12-13, and 24 Township 2 South, Range 12 West, Bay County and Sections 5-8, 18 and 19 of Township 2 South, Range 11 West, Calhoun County, east of Hwy 231,
and has a proposed mitigation service area incorporating portions of Bay, Calhoun, Franklin, Liberty, Gulf, Walton, Washington, Jackson, Gadsden Counties.
The application (#0294288-001) is being processed and is available for public inspection during normal business hours at the Department’s Office of Submerged Lands and Environmental Resources, Twin Towers Building, 2600 Blair Stone Road, MS 2500, Tallahassee, FL, 32399-2400.
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT OF THE STATE OF FLORIDA,
IN AND FOR CALHOUN COUNTY
CIVIL DIVISION
CASE NO: 08-326-CA
NATIONSTAR MORTGAGE LLC F/K/A CENTEX
HOME EQUITY COMPANY, LLC,
Plaintiff,
-vs-
REGINA ROY A/K/A REGINA TYLER A/K/A REGINA NICHOLE TYLER; THE UNKNOWN SPOUSE OF REGINA ROY A/K/A REGINA TYLER A/K/A REGINA NICOLE TYLER; CHRISTOPHER ROY; THE UNKNOWN SPOUSE OF CHRISTOPHER ROY; IF LIVING, INCLUDING ANY UNKNOWN SPOUSE OF SAID DEFENDANT(S), IF REMARRIED, AND IF DECEASED, THE RESPECTIVE UNKNOWN HEIRS, DEVISEES, GRANTEES, ASSIGNEES, CREDITORS, LIENORS, AND TRUSTEES, AND ALL OTHER PERSONS CLAIMING BY, THROUGH, UNDER OR AGAINST THE NAMED DEFENDANT(S); UNKNOWN TENANT #1; UNKNOWN TENANT #2;
Defendant(s)
NOTICE OF SALE
Notice is hereby given that, pursuant to a Final Summary Judgment of Foreclosure entered in the above-styled cause, in the Circuit Court of Calhoun County Florida, I will sell the property situate in Calhoun County, Florida, described as:
Begin at a point on the North side of State Road No. 20, said point being 411.5 feet North and 838.24 feet East of the Southwest corner of Southeast 1/4 of Northwest 1/4, Section 31, Township 1 North, Range 8 West, thence run East at an angle along the north line of State Road No. 20, 840 feet, thence run North to North line of Northwest 1/4 of Northeast 1/4 of Section 31, Township 1 1 North, Range 8 West, thence run West 68 feet for the POINT OF BEGINNING, thence run West 236 feet, thence run South 370 feet, thence run East 236 feet, thence run north 370 feet, to the POINT OF BEGINNING, of the Public Records of Calhoun County, Florida.
A/K/A
18926 NW Marchant Avenue
Blountstown, FL 32424
at public sale, to the highest and best bidder, for cash, Calhoun County Courthouse, 20859 SE Central Avenue East, Blountstown, FL 32424 at 11:00 A.M. CST on June 18, 2009
DATED at CALHOUN County this 13th day of May, 2009.
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the lis pendens, must filer a claim within 60 days after the sale.
WITNESS my hand and seal of this court on the 13th day of May, 2009.
Ruth W. Attaway
Clerk of Court
In accordance with the American with Disabilities Act of 1990, persons needing accommodation to participate in this proceeding should contact the ASA Coordinator no later than seven (7) days prior to the proceedings. If hearing impaired, please call (800) 955-9771 (TDD) or (800) 59-8770 (voice), via Florida Relay Service
Law Offices of Daniel C. Consuegra
9204 King Palm Drive
Tampa, FL 33619-1328
Tel: (813) 915-8660
Fax: (813) 915-0559
Attorney for Plaintiff
Legal Notice
IN THE CIRCUIT COURT FOR CALHOUN
COUNTY FLORIDA,
PROBATE DIVISION
File Number: PR09-32PR
IN RE:KENNETH BYRON JONES
Deceased.
NOTICE OF ADMINISTRATION AND
NOTICE OF CREDITORS
TO ALL PERSONS HAVING CLAIMS OR DEMANDS AGAINST THE ABOVE ESTATE AND ALL OTHER PERSONS INTERESTED IN THE ESTATE:
YOU ARE NOTIFIED that the administration of the Estate of Kenneth Byron Jones, File Number PR09-32PR is pending in the Circuit Court for Calhoun County, Florida, Probate Division, 20859 Central Ave., Blountstown, FL 32424, the address of which is the Calhoun County Courthouse, Blountstown, Florida. The Personal Representative of the Estate is Constance H. Jones. The name and address of the Personal Representative’s attorney are set forth below.
All persons having claims or demands against the Estate are required, WITHIN THREE MONTHS FROM THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE, to file with the Clerk of the above Court a written statement of any claim or demand they may have. Each claim must be in writing and must indicate the basis for the claim, the name and address of the creditor or his agent or attorney and the amount the claim is contingent or unliquidated, the nature of the uncertainty shall be state. If the claim is secured, the security shall be described. The claimant shall deliver sufficient copies of the claim to the Clerk to enable the Clerk to mail one copy to the Personal Representative. All persons interested in the Estate to whom a copy of this Notice of Administration has been mailed are required, WITHIN THREE MONTHS FROM THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE, to file any objection they may have that challenges the validity of the decedent’s Will, the qualifications of the Personal Representative, or the venue or jurisdiction of the Court.
DATED this 12th day of May, 2009.
CONSTANCE H. JONES
P.O. Box 69
Clarksville, FL 32430
J. DAVID HOUSE
16865 S.E. RIVER STREET
BLOUNTSTOWN, FLORIDA 32424
(850) 674-5481
FLORIDA BAR #282359
ATTORNEY FOR PERSONAL REP.
NOTICE TO RECEIVE SEALED BIDS
The Calhoun County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing:
SAM ATKINS PARK - RECREATION FIELD
LIGHTING
Plans and specifications can be obtained at Preble-Rish, Inc. 324 Marina Drive, Port St. Joe, Florida 32456, (850) 227-7200. The bid must conform to Section 287.133(3) Florida Statutes on public entity crimes.
This project consists of recreation field lighting at Sam Atkins Park.
Completion date for these projects will be 90 days from the date of the Notice to Proceed presented to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $200 per day.
Please indicate on the envelope that this is a sealed bid for RECREATION FIELD LIGHTING AT SAM ATKINS PARK.
Bids will be received until 12:00 p.m. CST on Tuesday, June 2, 2009, at the Calhoun County Clerk’s Office, Calhoun County Courthouse, 20859 Central Avenue East, Room 130, Blountstown, FL 32424, and will be opened and read aloud on Tuesday, June 2, 2009, at 2:00 p.m. CST.
Cost for Plans and Specifications will be $25.00 per set and is non-refundable. Checks should be made payable to Preble-Rish, Inc.
The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Calhoun County.
If you have any questions, please call Donald Stanley at (850) 643-2771 or Kim Tanner at (850) 674-4545.
Legal Notice
The Calhoun County School Board proposes to introduce and amend policies for Calhoun County Schools as follows:
ADMINISTRATIVE PROCEDURES ACT
CALHOUN COUNTY SCHOOLS
CHAPTER 2-SCHOOL BOARD GOVERANCY AND ORGANIZATION
CHAPTER 6-HUMAN RESOURCES
Introducing and Amending Policy:
Policy 6.13-Years of Service
Policy 6.531-DROP
Policy 6.92-Health Insurance Premiums
Policy 6.912-Terminal Sick Leave and Vacation Pay
Policy 2.221-Public Participation During Board Meetings
Most of these policy changes are necessitated by changes in statute citations by the State of Florida. The entire proposals are available for viewing at the School Superintendent’s Office, Room G-20, Calhoun County Court House, Blountstown, Florida.
A hearing will be held on the above policies in the Courthouse in Blountstown, Florida at the Regular School Board meeting on Tuesday, June 9, 2009 at 5:00 p.m.
Kelly King, Chairperson
Calhoun County School Board
Attest:
Wilson T. McClellan, Superintendent
Calhoun County Schools
“An Equal Opportunity Employer”
Legal Notice
IN THE CIRCUIT COURT FOR CALHOUN
COUNTY FLORIDA,
PROBATE DIVISION
File No. 09-28 PR
IN RE: ESTATE OF
GARY SAVAGE,
Deceased.
NOTICE TO CREDITORS
The administration of the estate of GARY SAVAGE, deceased, whose date of death was October 2, 2008, File Number 09-28 PR, is pending in the Circuit Court for Calhoun County, Florida, Probate Division, the address of which is 20859 Central Ave., E., Blountstown, Florida 32424. The names and addresses of the personal representative and the personal representative’s attorney are set forth below.
All creditors of the decedent and other persons having claims or demands against decedent’s estate, including unmatured, contingent or unliquidated claims, on whom a copy of this notice is served mule file their claims with this court WITHIN THE LATER OF THREE MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE OR THIRTY DAYS AFTER THE DATE OF SERVICE OF A COPY OF THIS NOTICE ON THEM.
All other creditors of the decedent and persons having claims or demands against the decedent’s estate including unmatured, contingent or unliquidated claims, must file their claims with this court WITHIN THREE MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE.
ALL CLAIMS, DEMANDS AND OBJECTIONS NOT SO FILED WILL BE FOREVER BARRED.
The date of the first publication of this Notice is May 6, 2009.
Personal Representative:
JAMES SAVAGE
2312 Coach Road
Argyle, NY 12809
DAMIEN SAVAGE
47 Saratoga Ave.
S. Glens Falls. NY 12803
Attorney for Personal Representative:
DENNIS J. O’CONNOR, ESQ.
Florida Bar No. 643297
MCPHILLIPS, FITZGERALD, CULLUM, L.L.P.
9165 Park Drive
Miami Shores, FL 33308
Telephone: (305) 751-8556
Legal Notice
IN THE CIRCUIT COURT OF THE
FOURTEENTH JUDICIAL CIRCUIT
IN AND FOR CALHOUN COUNTY, FLORIDA
CIVIC ACTION
CASE NO.: 07-2008-CA-000328
CHASE HOME FINANCE LLC,
Plaintiff,
-vs-
THE UNKNOWN HEIRS, DEVISEES,
GRANTEES, ASSIGNEES, LIENORS,
CREDITORS, TRUSTEES, OR OTHER
CLAIMANTS, CLAIMING BY,
THROUGH, UNDER, OR AGAINST DANIEL
COHEE, A/K/A DANIEL EDMUND COHEE
A/K/A DANIEL EDMOND COHEE, DECEASED,
et al,
Defendant(s)
NOTICE OF ACTION
TO;
MICHELLE LEE COHEE, AS AN HEIR OF THE ESTATE OF DANIEL COHEE A/K/A DANIEL EDMUND COHEE A/K/A DANIEL EDMOND COHEE, DECEASED
LAST KNOWN ADDRESS: 265 SUNSHINE SPRINGS COURT, HENDERSON, NV 89014
CURRENT ADDRESS: UNKNOWN
YOU ARE NOTIFIED that an action to foreclose a mortgage on the following property in CALHOUN County, Florida:
COMMENCE AT THE SOUTHWEST CORNER OF THE NORTHEAST QUARTER OF SECTION 6, TOWNSHIP 1 SOUTH, RANGE 8 WEST, CALHOUN COUNTY, FLORIDA AND RUN THENCE SOUTH 89 DEGREES 22 MINUTES 33 SECONDS EAST ALONG THE SOUTHERLY BOUNDARY OF SAID NORTHEAST QUARTER A DISTANCE OF 26.67 FEET TO THE EASTERLY RIGHT OF WAY BOUNDARY OF FAIRCLOTH ROAD (80 FOOT RIGHT OF WAY) AND THE POINT OF BEGINNING. FROM SAID POINT OF BEGINNING THENCE NORTH 00 DEGREES 39 MINUTES 51 SECONDS EAST ALONG SAID EASTERLY RIGHT OF WAY BOUNDARY A DISTANCE OF 330.99 FEET TO THE NORTHERLY BOUNDARY OF THE SOUTH HALF OF THE SOUTHWEST QUARTER OF THE SOUTHWEST QUARTER OF SAID NORTHEAST QUARTER; THENCE SOUTH 89 DEGREES 22 MINUTES 21 SECONDS EAST ALONG SAID NORTHERLY BOUNDARY A DISTANCE OF 130.00 FEET; THENCE SOUTH 00 DEGREES 39 MINUTES 51 SECONDS WEST 330.98 FEET TO THE AFORESAID SOUTHERLY BOUNDARY OF THE NORTHEAST QUARTER; THENCE NORTH 89 DEGREES 22 MINUTES 33 SECONDS WEST ALONG SAID SOUTHERLY BOUNDARY A DISTANCE OF 130.00 FEET TO THE POINT OF BEGINNING.
TOGETHER WITH 1 2003 FLEETWOOD DOUBLEWIDE MOBILE HOME BEARING ID NO. GAFL275A74414-CD21 AND GAFL275B74414-CD21, LYING AND BEING SITUATE THEREON. TOGETHER WITH THAT CERTAIN MOBILE HOME LOCATED THEREON AS A FIXTURE AND APPURTENANCE THERETO.
has been filed against you and you are required to serve a copy of your written defenses within 30 days after the first publication, if any, on Florida Default Law Group, P.L., Plaintiff’s attorney, whose address is 9119 Corporate Lake Drive, Suite 300, Tampa, Florida 33634, and file the original with this Court either before service on Plaintiff’s attorney or immediately thereafter; otherwise a default will be entered against you for the relief demanded in the Complaint or petition.
This notice shall be published each week for two consecutive weeks in The County Record.
WITNESS my hand and the seal of this Court on this 7th day of May, 2009.
RUTH W. ATTAWAY
CLERK OF THE COURT
Legal Notice
IN THE CIRCUIT COURT OF THE
FOURTEENTH JUDICIAL CIRCUIT
IN AND FOR CALHOUN COUNTY, FLORIDA
CIVIC ACTION
CASE NO.: 07-2008-CA-000272
CHASE HOME FINANCE LLC,
Plaintiff,
-vs-
KRISTINA L. SUTHERLAND, et al.,
Defendant(s)
NOTICE OF FORECLOSURE SALE
NOTICE IS HEREBY GIVEN pursuant to a Final Judgment of Mortgage Foreclosure dated May 06, 2009 and entered in Case No. 07-2008-CA-000272 of the Circuit Court of the FOURTEENTH Judicial Circuit in and for CALHOUN County, Florida where CHASE HOME FINANCE LLC, is the Plaintiff and KRISTINE L. SUTHERLAND; BARBARA L. SUTHERLAND; AND ANY AND ALL UNKNOWN PARTIES CLAIMING BY, THROUGH, UNDER, AND AGAINST THE HEREIN NAMED INDIVIDUAL DEFENDANT(S) WHO ARE NOT KNOWN TO BE DEAD OR ALIVE, WHETHER SAID UNKNOWN PARTIES MAY CLAIM AN INTEREST AS SPOUSE, HEIRS, DEVISEES, GRANTEES, OR OTHER CLAIMANTS; are the Defendants, I will sell to the highest and best bidder for cash at LOBBY OF THE CALHOUN COUNTY COURTHOUSE at 11:00 AM CST, on the 25th day of June, 2009, the following described property as set forth in said Final Judgment:
COMMENCE AT A 6 INCH SQUARE CONCRETE MONUMENT MARKING THE SOUTHWEST CORNER OF SECTION 35, TOWNSHIP 2 NORTH, RANGE 11 WEST, CALHOUN COUNTY, FLORIDA AND RUN THENCE NORTH 89 DEGREES 22 MINUTES 27 SECONDS WEST ALONG THE SOUTHERLY BOUNDARY OF SAID SECTION 35 A DISTANCE OF 1647.39 FEET TO THE SOUTHEAST CORNER OF THE WEST HALF OF THE SOUTHEAST QUARTER OF THE SOUTHWEST CORNER OF THE SOUTHEAST QUARTER OF SAID SECTION 35 AND THE POINT OF BEGINNING. FROM SAID POINT OF BEGINNING THENCE NORTH 00 DEGREES 28 MINUTES 28 SECONDS WEST 134.97 FEET THENCE NORTH 89 DEGREES 34 MINUTES 05 SECONDS WEST 329.83 FEET THENCE SOUTH 00 DEGREES 38 MINUTES 06 SECONDS EAST 133.86 FEET TO SAID SOUTHERLY BOUNDARY; THENCE SOUTH 89 DEGREES 22 MINUTES 27 SECONDS EAST ALONG SAID SOUTHERLY BOUNDARY A DISTANCE OF 329.48 FEET TO THE POINT OF BEGINNING. WHICH INCLUDES THAT CERTAIN 2007 KING MODEL NO. 44E3H, NOBILITY MANUFACTURED HOME, SERIAL NO. N813072A/N813072B, WHICH IS ATTACHED AND MADE A PART OF THE REAL PROPERTY. WHICH, BY INTENTION OF THE PARTIES AND UPON RETIREMENT OF THE CERTIFICATE OF TITLE AS PROVIDED IN 319.261 FLORIDA, STATUTES, SHALL CONSTITUTE A PART OF THE REALTY AND SHALL PASS WITH IT.
A/K/A 5142 NW MILLER ROAD, ALTHA, FL 324210000
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the Lis pendens must file a claim within sixty (60) days after the sale.
WITNESS MY HAND and the seal of this Court on May 8, 2009.
Ruth W. Attaway
Clerk of the Circuit Court
WITNESS MY HAND and the sale of this Court on March 5, 2008.
Ruth W. Attaway
Clerk of the Circuit Court
March 12, 19, 2008
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT OF THE STATE OF FLORIDA,
IN AND FOR CALHOUN COUNTY
CIVIL DIVISION
CASE NO: 08-266-CA
CITIMORTGAGE, INC.,
Plaintiff,
-vs-
SAMUEL GEORGE HAYSLIP, III A/K/A SAMUEL HAYSLIP; UNKNOWN SPOUSE OF SAMUEL GEORGE HAYSLIP, III A/K/A SAMUEL HAYSLIP; ANGELINA ALICE HAYSLIP; UNKNOWN SPOUSE OF ANGELINA ALICE HAYSLIP; IF LIVING, INCLUDING ANY UNKNOWN SPOUSE OF SAID DEFENDANT(S), IF REMARRIED, AND IF DECEASED, THE RESPECTIVE UNKNOWN HEIRS, DEVISEES, GRANTEES, ASSIGNEES, CREDITORS, LIENORS, AND TRUSTEES, AND ALL OTHER PERSONS CLAIMING BY, THROUGH, UNDER OR AGAINST THE NAMED DEFENDANT(S); UNKNOWN TENANT #1; UNKNOWN TENANT #2;
Defendant(s)
NOTICE OF SALE
Notice is hereby given that, pursuant to a Final Summary Judgment of Foreclosure entered in the above-styled cause, in the Circuit Court of Calhoun County Florida, I will sell the property situate in Calhoun County, Florida, described as:
COMMENCE AT THE INTERSECTION OF THE CENTER L INE OF SR #274 AND THE EAST LINE OF SECTION 16, TOWNSHIP 2 NORTH, RANGE 9 WEST, CALHOUN COUNTY, FLORIDA (DEPARTMENT OF TRANSPORTATION STATION 281 + 29.07); THENCE NORTH 89 DEGREES 17 MINUTES 57 SECONDS WEST ALONG SAID CENTER LINE 1815.44 FEET TO THE P.T. (STATION 263. + 13.63); THENCE CONTINUE NORTH 89 DEGREES 17 MINUTES 57 SECONDS WEST 383.88 FEET TO A CONCRETE MONUMENT ON THE NORTHERLY RIGHT OF WAY OF SAID, ROAD AND CALL THIS THE POINT OF BEGINNING; THENCE CONTINUE NORTH 89 DEGREES 17 MINUTES 57 SECONDS WEST 651.20 FEET TO A CONCRETE MONUMENT; THENCE SOUTH 08 DEGREES 32 MINUTES 03 SECONDS WEST 200.00 FEET TO A CONCRETE MONUMENT; THENCE SOUTH 03 DEGREES 04 MINUTES 48 SECONDS WEST 171.27 FEET TO A CONCRETE MONUMENT ON THE WESTERLY RIGHT OF WAY OF SR #274; THENCE NORTH 55 DEGREES 46 MINUTES 21 SECONDS EAST ALONG SAID RIGHT OF WAY 228.45 FEET TO THE P.C. OF A CURVE (D.O.T. STATION 254 +39.05); THENCE CONTINUE ALONG SAID RIGHT OF WAY A CONCAVE TOWARDS THE RIGHT HAVING A DELTA ANGLE OF 18 DEGREES 42 MINUTES 30 SECONDS A RADIUS OF 1699.28 FEET: AN ARC DISTANCE OF 554.85 FEET TO THE POINT OF BEGINNING.
A/K/A
15006 NW COUNTY ROAD #274
ALTHA, FL 32421
at public sale, to the highest and best bidder, for cash, Calhoun County Courthouse, 20859 SE Central Avenue East, Blountstown, FL 32424 at 11:00 A.M. CST on June 11, 2009.
DATED at CALHOUN County this 30th day of July, 2008.
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the lis pendens, must filer a claim within 60 days after the sale.
WITNESS my hand and seal of this court on the 6th day of May, 2009.
Ruth W. Attaway
Clerk of Court
In accordance with the American with Disabilities Act of 1990, persons needing accommodation to participate in this proceeding should contact the ASA Coordinator no later than seven (7) days prior to the proceedings. If hearing impaired, please call (800) 955-9771 (TDD) or (800) 59-8770 (voice), via Florida Relay Service
Law Offices of Daniel C. Consuegra
9204 King Palm Drive
Tampa, FL 33619-1328
Tel: (813) 915-8660
Fax: (813) 915-0559
Attorney for Plaintiff
Legal Notice
INVITATION TO BID
Sealed bids will be received by the Calhoun County School Board until 5:00 P.M., CDT, Tuesday, June 9, 2009, for the purchase of the following:
LP Gas for use in lunchrooms and schools of Calhoun County.
Gasoline and Diesel for use in the operation of public vehicles, school buses and school plants.
Any additional information or bid forms required may be obtained at the Office of the School Superintendent, 20859 Central Ave. E., Rm. G-20, Blountstown, Florida. Bid forms must be used by each bidder submitting a bid. Otherwise bids will not be considered.
Any bid submitted after the specified hour and date will not be opened or considered. The Board accepts no responsibility for mailed proposals that arrive at the Superintendent’s Office after the above stated time, even though the envelope may reflect a postmark prior to the above date.
The Board reserves the right to accept or reject any or all bids. The decision of the Board will be final. No bid may be withdrawn by any bidder for a period of thirty (30) days after bids are opened.
Kelly King, Chairman
Calhoun County School Board
ATTEST:
Tommy McClellan, Superintendent
Calhoun County Schools
Legal Notice
Public Auction
Mallory Towing and Recovery Inc. will hold a public auction on, May 29, 2009 at 2:00 (P.M.) on a:
1996 Hyundai, 4 Door, White in Color
Vin#KMHJF24MXTU199594
Auction will be held at Mallory Towing and Recovery Inc. at 17311 NE Pear Street, in Blountstown FL., 850-674-2869.
Mallory Towing and Recovery Inc. reserves the right to reject any and all bids.
Legal Notice
State of Florida
Department of Environmental Protection
NOTICE OF APPLICATION
The Department announces receipt of an application for a permit to create a 3,030-acre mitigation bank known as the Bear Creek Mitigation Bank in four phases. The application is submitted by Mr. Tom Odom, authorized agent, Mitigation Resources, LLC, 713 Montrose St., Clermont, FL 34711 for the applicant Bear Creek Timber, LLC represented by Matthew Whitley. The mitigation plan includes the restoration or enhancement and preservation of onsite uplandflatwoods and bay swamp communities to earn credits with the potential to offset impacts to wetland resources within the service area. Enhancement will be accomplished by the construction of ditch blocks and low water crossings and by the removal of inappropriate vegetation, establishment of prescribed fires, and long term management. This project is located in Sections 12-13, and 24 Township 2 South, Range 12 West, Bay County and Sections 5-8, 18 and 19 of Township 2 South, Range 11 West, Calhoun County, east of Hwy 231,
and has a proposed mitigation service area incorporating portions of Bay, Calhoun, Franklin, Liberty, Gulf, Walton, Washington, Jackson, Gadsden Counties.
The application (#0294288-001) is being processed and is available for public inspection during normal business hours at the Department’s Office of Submerged Lands and Environmental Resources, Twin Towers Building, 2600 Blair Stone Road, MS 2500, Tallahassee, FL, 32399-2400.
Legal Notice
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT OF THE STATE OF FLORIDA,
IN AND FOR CALHOUN COUNTY
CIVIL DIVISION
CASE NO: 08-326-CA
NATIONSTAR MORTGAGE LLC F/K/A CENTEX
HOME EQUITY COMPANY, LLC,
Plaintiff,
-vs-
REGINA ROY A/K/A REGINA TYLER A/K/A REGINA NICHOLE TYLER; THE UNKNOWN SPOUSE OF REGINA ROY A/K/A REGINA TYLER A/K/A REGINA NICOLE TYLER; CHRISTOPHER ROY; THE UNKNOWN SPOUSE OF CHRISTOPHER ROY; IF LIVING, INCLUDING ANY UNKNOWN SPOUSE OF SAID DEFENDANT(S), IF REMARRIED, AND IF DECEASED, THE RESPECTIVE UNKNOWN HEIRS, DEVISEES, GRANTEES, ASSIGNEES, CREDITORS, LIENORS, AND TRUSTEES, AND ALL OTHER PERSONS CLAIMING BY, THROUGH, UNDER OR AGAINST THE NAMED DEFENDANT(S); UNKNOWN TENANT #1; UNKNOWN TENANT #2;
Defendant(s)
NOTICE OF SALE
Notice is hereby given that, pursuant to a Final Summary Judgment of Foreclosure entered in the above-styled cause, in the Circuit Court of Calhoun County Florida, I will sell the property situate in Calhoun County, Florida, described as:
Begin at a point on the North side of State Road No. 20, said point being 411.5 feet North and 838.24 feet East of the Southwest corner of Southeast 1/4 of Northwest 1/4, Section 31, Township 1 North, Range 8 West, thence run East at an angle along the north line of State Road No. 20, 840 feet, thence run North to North line of Northwest 1/4 of Northeast 1/4 of Section 31, Township 1 1 North, Range 8 West, thence run West 68 feet for the POINT OF BEGINNING, thence run West 236 feet, thence run South 370 feet, thence run East 236 feet, thence run north 370 feet, to the POINT OF BEGINNING, of the Public Records of Calhoun County, Florida.
A/K/A
18926 NW Marchant Avenue
Blountstown, FL 32424
at public sale, to the highest and best bidder, for cash, Calhoun County Courthouse, 20859 SE Central Avenue East, Blountstown, FL 32424 at 11:00 A.M. CST on June 18, 2009
DATED at CALHOUN County this 13th day of May, 2009.
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the lis pendens, must filer a claim within 60 days after the sale.
WITNESS my hand and seal of this court on the 13th day of May, 2009.
Ruth W. Attaway
Clerk of Court
In accordance with the American with Disabilities Act of 1990, persons needing accommodation to participate in this proceeding should contact the ASA Coordinator no later than seven (7) days prior to the proceedings. If hearing impaired, please call (800) 955-9771 (TDD) or (800) 59-8770 (voice), via Florida Relay Service
Law Offices of Daniel C. Consuegra
9204 King Palm Drive
Tampa, FL 33619-1328
Tel: (813) 915-8660
Fax: (813) 915-0559
Attorney for Plaintiff
Legal Notice
IN THE CIRCUIT COURT FOR CALHOUN
COUNTY FLORIDA,
PROBATE DIVISION
File Number: PR09-32PR
IN RE:KENNETH BYRON JONES
Deceased.
NOTICE OF ADMINISTRATION AND
NOTICE OF CREDITORS
TO ALL PERSONS HAVING CLAIMS OR DEMANDS AGAINST THE ABOVE ESTATE AND ALL OTHER PERSONS INTERESTED IN THE ESTATE:
YOU ARE NOTIFIED that the administration of the Estate of Kenneth Byron Jones, File Number PR09-32PR is pending in the Circuit Court for Calhoun County, Florida, Probate Division, 20859 Central Ave., Blountstown, FL 32424, the address of which is the Calhoun County Courthouse, Blountstown, Florida. The Personal Representative of the Estate is Constance H. Jones. The name and address of the Personal Representative’s attorney are set forth below.
All persons having claims or demands against the Estate are required, WITHIN THREE MONTHS FROM THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE, to file with the Clerk of the above Court a written statement of any claim or demand they may have. Each claim must be in writing and must indicate the basis for the claim, the name and address of the creditor or his agent or attorney and the amount the claim is contingent or unliquidated, the nature of the uncertainty shall be state. If the claim is secured, the security shall be described. The claimant shall deliver sufficient copies of the claim to the Clerk to enable the Clerk to mail one copy to the Personal Representative. All persons interested in the Estate to whom a copy of this Notice of Administration has been mailed are required, WITHIN THREE MONTHS FROM THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE, to file any objection they may have that challenges the validity of the decedent’s Will, the qualifications of the Personal Representative, or the venue or jurisdiction of the Court.
DATED this 12th day of May, 2009.
CONSTANCE H. JONES
P.O. Box 69
Clarksville, FL 32430
J. DAVID HOUSE
16865 S.E. RIVER STREET
BLOUNTSTOWN, FLORIDA 32424
(850) 674-5481
FLORIDA BAR #282359
ATTORNEY FOR PERSONAL REP.
Trackbacks
Trackback specific URI for this entry
No Trackbacks